HomeMy WebLinkAboutGLE Agreement 2011AGREEMENTFOR
CONTINUING ARCHITECTURAL SERVICES
THIS AGREEMENT is made and entered this '�-/ dayof .2011, by and
between the CITY OF CAPE CANAVERAL, FLOREDA, a Florida municipal corporation
("Citv") located at 105 Polk Avenue Caie 6aniveri.], Flifia 32Q, i" A "I' TATES.
�-UJVSII
it Tampa, Florida 33607.
WITNESSETH:
WHEREAS, City has a need to obtain architectural services from time to time on an as -
needed, task -oriented basis; and
I
MMMMI IN ,
III III I III Jill I I
MA191 � 1� Ull t 101 M1111111:11111114LZ .1 111111 1 Jill , Jill III p
01 ME J-1811121111MV141016i I I MMMIZM��
WHEREAS, Consultant is willing to provide such architectural services to the City under the
terms and conditions stated herein.
li Will MUS I U-11MUMAMIN HUMM
o.% I mr-A list a I
I ave the option to extend the term for two (2) additional one (1) year renewals. Such an extension
shall only be by written amendment to this Agreement executed by both parties hereto.
1.2 The terms and conditions of any Task Order, r,. in Section 2 hereof, shall b%
as set forth in such Tas]LO-rder
tt -ey&Tj-U yas-k ASM er,-qAd -qR DLAe-tJJx-.J �#, TAYk*Tes-� "P-,ccmj
shall survive until completion of all Task Orders.
1.3 Derinitions. The following words and phrases used in this Agreement shall have the
following meaning ascribed to them unless the context clearly indicates otherwise:
a. "Agreement" or "Contract" shall be used interchangeably and shall refer to this
AL-reement. as amende
Citv rif C.?r-- ("Frtig-veral / GLF kssticiates- Nile-
PTUM 77714. is NMI sometrues rererrea
to herein to include all Task Orders approved hereunder.
b. "Effective Date" shall be the date on which the last signatory hereto shall execute this
Agreement, and it shall be the date on which this Agreement shall go into effect. The Agreement
shall not go into effect until said date.
C. "Consultant" shall mean GLE Associates, Inc. and its principals, employees, resident
project representatives (and assistants).
d. 'Tublic Recor&' shall have the meaning given in section 119.011(12), Florida S tatutes
as may be amended.
e. "Reimbursable Expenses" shall mean the actual expenses incurred by Consultant or
WMEN M0 MU -1 us VII -I
f. 44worleor "Services" shall be used interchangeably and shall include the performance
of the work agreed to by the parties in a Task Order.
9- "Task Ordee' shall mean a written document approved by the parties pursuant to th*
procedure outlined in paragraph 2.0 of this Agreement, and any amendments thereto approv,"-
pursuant to the procedures outlined in paragraph 3.0 herein, which sets forth the Work to be
y,erformed-b-ir, Consultant under this #-,f owcmt-
reference, the terms and conditions of this Agreement.
1.4 Engagement. The City hereby engages the Consultant and Consultant agrees to
perform the Services outlined in this agreement for the stated fee arrangement. No prior or present
1 11 11 0 1 1 MIN 01 IMU am
2.1 The City shall make request of Consultant to perform architectural services on a
AasV basis. The City will communicate with Consultant, verbally or in writing, a general
description of the task to be performed. The Consultant will generate a detailed Scope of Work
document7
the task, and send the thus developed "Task Proposal" to the City. The detailed cost breakdown of
the luml. sum fee shall consist of a list of ma; or sub -tasks and a man-hour breakdown for all work to
be performed. The cost breakdown shall include all sub -consultant work and the Task Proposal shall
include the written price proposals from aH sub -consultants. The detailed cost breakdown shall
—
JA
NT PAR M
Citv of Caoe Canaveral GLE Associate- T-
reimbursement. The City will review the Task Proposal, and if the description is mutual
acceptable, the parties will enter into a written "Task Order." The Scope of Services generally toIF
project and may contain written terms and conditions which are deemed supplemental to t
Agreement. I
The City will issue a notice to proceed to the Consultant in the form of a letter and an
executed City purchase order. Upon receipt of the signed Task Order and the written notice to
proceed from the City, the Consultant shall perform the services set forth in the Task Order.
3.1 City may make changes in the Services at any time by gg written notice to
Consultant. If such changes increase (additional services) or decrease or eliminate any amount of
Work. Ci6 and ConsultpnL��gotiate any changad �mst_or_s cheduleinodification&-Ifthe.
M77M. Tac CUITSTIERTIL appro To Raj (;uUr1g-V=#Vt
changes; and Consultant shall be compensated for said services in accordance with the terms of
Article 5.0 herein. All change orders shall be authorized in writing by City's and Consultant's
designated representative.
3.2 All of City's said Task Orders and amendments thereto shall be perfonned in strict
accordance with the terms of this Agreement insofar as they are applicable.
I
4.1 Consultant shall perform services in conformance with the mutually agreed schedule
set forth in the negotiated Task Order. Consultant shall complete all of said services in a timely
reasonably requested by the City. Should Consultant fall behind the agreed upon schedule, it shall
employ such resources so as to comply with the agreed-upon schedule.
4.2 No extension for completion of services shall be granted to Consultant without City's
N rior written consent, except as provided in Sections 3.1 and 19.1 herein.
4.3 Any cost caused by defective or ill-timed services shall be borne by the party
responsible therefore.
City of Cape Canaveral GLE Associates, Inc.
3
5.0 METHODS OF PAYMENT FOR SERVICES AND EXPENSES OF
CONSULTANT
5.1 General Services. For basic and additional Services performed by Consultant's
a particular Task Order. However, payment terms must be consistent with the terms and conditions
in this Agreement. To the extent that the payment terms in any Task Order conflict with the payment
terms set forth in this Agreement, the conflicting provisions of this Agreement shall prevail.
5.2 Addonal Services Performed by Professional Associates and Consultants. For
additional Services and Reimbursable Expenses of independent professional associates and
professional associates and consultants. Prior to payment by the City, the Consultant shall submit to
5.3 Witness Services. For witness or expert services rendered by ConsultanVs principals,
—assisqu-M"ud ixdepe
and consultants on behalf of the City in any litigation, arbitration, or other legal or interested
ZP
administrative proceeding in which the City is a named interested party, City agrees to pay the
C*isultv-j*o?r i-ii-.er.-tidem*,rtifessiviaI ass*ci7-te 4T C*-ISUltZtt,VJYi6L is used as a witxess *r expeyq
an amount equal to that agreed upon by the party for a particular Task Order.
5.4 Florida Prompt Payment Act. Payment shall be due and payable as provided by the
Florida Prompt Payment Act section 218.70 et. seq., Florida Statutes.
5.5 Miscellaneous. Under no circumstances shall actual or direct costs under this
Agreement include costs associated with in efficiency, offisite. or home office overhead, loss of
in whole or in part by the Consultant.
5.6 Errors and Deficiencies. Consultant shall not invoice th'
a A
eion from the City to correct or revise any errors or deficiencies in Consultant's services
provided under this Agreement.
5.7 Payment Offsets. To the extent that Consultant owes the City any money under this
or any other Agreement with the City, the City shall have the right to withhold payment and
otherwise back charge the Consultant for any money owed to the City by Consultant.
City of Cape Canaveral / GLE Associates, Inc.
4
not. o7consT77TV or operate as a7mrermj. My nglILS LIIILCr LIU, ^,gTUCTnUTIL Or MY CdMe Of UCEIOn
UU;UILAUCC TTILII-WP�JIIIUkLJ?Ie IMV 101- WI tWYW?�CS LU UIC k-UJUALNU-J, NJ UVIISLILUIR S fCI:IUI-ftD-U1GC 01
any services provided under this Agreement.
5.9 Delay Remedy The risk of any monetary damages caused by any delays in
M14" W-
4-UJL%-Q-f0JL cxv-rvl—a�rtwi PUIMMUINT
made or recognized. Consultant shall not make any claim nor seek any damages of any kind against
the Ci
foradel shall bean equitable extension Qf tim
that impacts the critical path of the schedule established under this Agreement or specific Task
Orter.
511�, a C" IN 0 axle
® it or its affiliates shall at all times have the right to review or observe the Services
performed by Consultant.
6.2 No inspection, review, or observation shall relieve Consultant of its responsibility
under this Agreement.
7.1 City's designated Project Manager may hold periodic progress meetings on a monthly
basis, or more frequently if required by the City, during the term of any Task Order entered into
,.IIIV"Iv4IU-I%IIII-29U=ItwI W -M-111 EWA,
8.1 Consultant shall be solely and absolutely responsible and assume all liability for the
safe v and supervision o " , " ch II I I
while performing Services provided hereunder.
r1107FIN "i'm
City of Cape Canaveral / GLE Associates, Inc -
5
10.0 INSURANCE
141
a. Professional Liability. Proof of professional liability insurance shall be provided to
the City for the minimum amount of $ 1,000,000 as the combined single limit per claim and
$1,000,000 in the aggregate.
b. General Liability. The Consultant -shall maintain comprehensive general liability
insurance in the minimum amount of $1.000.000 er occurrenck "20 O,JR
jigregate for bodil
Y-F-auqgC77177 =-111dj ITT 1.14-111 WIJ L.A.IS iYgECC 1 1
whether such Services are performed by the Consultant or by anyone directly employed by or
contractinF with the Consultant.
C. Automobile Liability. The Consultant shall maintain comprehensive automobile
liabilit-,y, insurance in the minimum amount of S-LOMDOO ger occurrence c9,m!,?,ined-v-ingle limit f9x
F
V. 24, *1116101111
116 NO
01*0 11 EJ) I hilli'MOVA14 ^ 0 IM 401MIR 1104111-1
d. Workers' Compensation. The Consultant shall maintain, during the life of this
Agreement, adequate Workers' Compensation Insurance and Employers' Liability Insurance in at
least such amounts as are required by law for all of its employees performing Work for the City
pursuant to this Agreement.
10.2 Special Requirements. Current, valid insurance policies meeting the requiremen
herein identified shall be maintained during the term of this Agreement. Renewal certificates sh
be sent to the City thirty (30) days prior to any expiration date. There shall also be a thirty (30) d
I M 600
j, y.
10.3 The insurance required by this Agreement shall include the liability and covera
provided herein, or as required by law, whichever requirements afford greater coverage. All of t
policies of insurance so required to be purchased and maintained shall contain a provision
ly-6-aigediv, r
iii r-iko-
I I-- IN
6ity of Cape Canaveral / GLE Associates, Inc.
6
insurance. It is expressly agreed that neither the provision of the insurance referred to in this
Agreement nor the City's acceptance of the terms, conditions or amounts of any insurance policy
shall be deemed a warranty or representation as to adequacy of such coverage. All insurance
coverap,a Willow
in the business of wrng of insurance or provided through the London Market for Professional
Liability Insurance. Unless agreed to by the City to the contrary, the City shall be named on the
insurance policies included in article 101b and 101c as "additional insured." The Consultant shall
cause its insurance carriers, prior to the effective date of this agreement to furnish insurance
certificates sieci6ing the t"111131es ani W- 691,661 )1
- H- -
thirty (30) days' prior written notice to the City in compliance with other provisions of this
Agreement. Further copies of all relevant policies will be provided to the City within thirty (30) days
of the effective date of this agreement. If the City has any objection to the coverage afforded by of
other provision of the insurance required to be purchased and maintained by the Consultant in
accordance with this Article on the basis of its not co-trmlvi-c.Ly witt. tke1=e.%-Tt,-e-Ftt-fVe
c iticates to the city. Vor 11 IT.,orK pertormed pursuant to this Agreement, the Consultant shall
continuously maintain such insurance in the amounts, type, and quality as required by the
Agreement.
10.4 Independent Associates and Consultants. All independent associates and
consultants
ig 3, Q. "I --.. rw
insurance provisions contained in this paragraph.
11.1 Consultant shall comply with all requirements of federal, state, and local laws, rules,
cegulations, standards, and/or ordinances applicable to the performance of Services under this
Aareement.
n
12.1 Consultant represents that the Services provided hereunder shall conform to all
reauirements. of this A greement and arny Task Order, shall be consistent with recQgni zed and-s"!Ad
architectural opractices and
and dgence appropriate to the nature of the Services rendered. Consultant shall perform as
ex2��fiti,*Vsly as is caasistem-witk yr*,fessiohol slill 2ni- cvrt aid 6ie;orierlyyrogmss *f the Serf ices
performed hereunder. Consultant's services shall be consistent with the time periods established
under this Agreement or the applicable Task Order. Consultant shall provide City with a written
schedule for services Derformed under . . ,
9 W10"
I I I I I L,ds &) 0 4 WAL"A VA 0D QV I I # &- 0 oil I - RiumpJ11*1111 JII I I 11110i
Eity of Cape Canaveral / GLE Associates, Inc.
7
submissions by authorities having jurisdiction over the services. The Consultant' S designate
representative shall have the authority to act on Consultant's behalf with respect to the Services. I
addition, Consultant's representative shall render decisions in a timely manner in order to avoli
unreasonable delay in the orderly and sequential progress of the Services. Except with the City
UYM=
4 -Th
judgment with respect to the Services. The Consultant shall review laws, codes, and regulatior
applicable to Consultant's Services. The Consultant's services and design shall comply with a
applicable requirements imposed by all public authorities. The Consultant represents and warrani
that it is familiar with, and accepts that it will perform the Services hereunder in a manner ft
complies with all applicable requirements of law, codes, and regulations. Consultant shall b
re s p o n s i b I c f or th e 9 ro fe s s i o n aLqu al i t ��- �', 2,rzru����& f aD ;I I wAw_
reports and other services furnished to the City under this Agreement. Unless this Agreement i
terminated bi the CWi r nonimeni if inv iiwte *
or terminated b Consult -ant fo it voi re-,_ or Ot
shall be responsible for the satisfactory and complete execution of theServices described in
J_ ,
the sc
Agreement and any Task Order. The Consultant represents that it will carefully examine 7 op -
RAM
material at its disposal to comilete the services set forth in the Task Order in a gaod mofession*
"M 4 Iwo 1111 VOW Will It -i all 1"M LOM 1IN11014DRIV11411129 .7-3
12.2 Consultant represents that all principals, employees, and other personnel furnishing
such Services shall be qualified and competent to perform the Services assigned to them and tha-i
sa& gt0__?,iwP__gWtx► tIc-=* I
their best professional knowledge and judgment.
"O11MU01W., 1 i 11' 1� ;� � �i �!�� �� �� 11 �g �1� 11�� ��� 11� � ] I 1IR ( JV3
13.1 Consultant guarantees that all Services performed under this Agreement shall be free
from claims of patent, copyright, and trademarks infringement. Notwithstanding any other provision
of this Agreement, Consultant shall indemni hold harmless and defend Cii, its officers, directors.
kgal or otherwise, for actual or alleged infringenmat.! X
Jk1t;;,L
from the use of any goods, Services, or other item provided under this Agreement. Notwithstanding
the foregoing, Consultant may elect to provide non -infringing services.
14.1 Public Records. It is hereby specifically agreed that any record, document,
computerized information and program, audio or video tape, photograph, or other writing of the
Consultant and its independent contractors and associates related, directly or indirectly, to this
6ity of Cape Canaveral 1 GLE Associates, Inc.
8
���the�n al�-ronifctl
City. All books, cards, registers, receipts, documents, and other papers in connection with th
Agreement shall at any and all reasonable times during the normal working hours of the Consulta.
be open and freely exhibited to the City for the purpose of examination and/or audit.
a. Reuse of Documents. All documents, including but not limited to, dtawin
i" i' and data ouproffams stored electronical or itherwise,.-o=1 dJ
the Services described herein shall be owned by the City and may be reused by the City for a
reason or purpose at anytime. However, the City agrees that the aforesaid documents are n
intended or represented to be suitable for reuse by the City or others on any undertaking other th
the W 9MI-r@ **ffy- "-J1rqv'.
verification or adaptation by the Consultant, or its independent contractors and associates
necessary, to specific purposes intended will be at the City's sole risk and without liability or leg
expMsure to the Consultant.
"DIM
WA M-
I"." j I LLWJ Ll VU 11 IMP
li-s—L-compilation. drawing, specification -apj-dahru- uitclgL
L w-jr
instrument produced by the Consultant in the performance of this Agreement, or any Work
hereunder, shall be the sole property of the City, and the City is vested with all rights therein. The
Consultant waives all ri-ghts of coDwi
Consultant in the performance of this Agreement, and hereby assigns and conveys the same to the
City whether in the possession or control of the Consultant or not.
C. Preexisting Ownership Rights to Documents. Notwithstanding any provisions to
the contrary contained in this Agreement, Consultant shall retain sole ownership to its preexisting
4 fo ma ati *:L x * t yr* du c e tz:k, -11, qJ4 f *&ky t ke Ci ty u x dexA- i s A gc e eaex t ixcl P, i, �xg, If, V, t X *t UMj te4,t,*,.
c.omputer programs, software, standard details, figures, templates and specifications.
15.0 ASSIGNMENT
15.1 Consultant shall not assign or subcontract this Agreement, any Task Order hereund
or any rights or any monies due or to become due hereunder without the prior, written consent
City. I
Citv of C-vve Ca -f averal GLF 1-,,qqocinteg- htc-
15.2 If upon receiving written approval from City, any part of this Agreement is
subcontracted by Consultant, Consultant shall be fully responsible to City for all acts and/or
omissions performed by the subcontractor as if no subcontract had been made.
15.3 If City determines that any subcontractor is not performing in accordance with this
15.4 If any part of this Agreement is subcontracted by Consultant, prior to thf,
commencement of any Work by the subcontractor, Consultant shall require the subcontractor to
provide City and its affiliates with insurance coverage as set forth by the City.
OE �� ij�� ; � l
MM1 1111 �i i", � 71
16.1 At all times during the term of this Agreement, Consultant shall be considered an
Independent contractor and not an employee of the City.
01a) 1,01 Oil
17.1 The City reserves the right to revoke and terminate this Agreement and rescind all
rights and privileges associated with this Agreement, without penalty, in the following
circumstances, each of which shall represent a default and breach of this Agreement:
17.2 Consultant defaults in the performance of any material covenant or condition of this
.4 t Li%iw-wy-gjA &mr% gxw4j o4t e*i A-4,y�Ay?,iWt LB&A�&AARj IeLgLdd
ip 1111111111 11
1W 111 IBM -
which case the Consultant shall have such time as is reasonably necessary to remedy the default,
provided the Consultant promptly takes and diligently pursues such actions as are necessary
therefore; or
17.3 Consultant is adjudicated bankrupt or makes any assigm-nent for the benefit of
creditors or Consultant becomes insolvent, or is unable or unwilling to pay its debts; or
17.4 Consultant has acted grossly negligent, as defined by general and applicable law,
performing the Services hereunder; or i
17.6 Consultant has made a material misrepresentation of fact to the City while performing
Ets obligations under this Agreement.
I---- M7 -17M
6ity of Cape Canaveral / GLE Associates, Inc.
10
11;1�11qiii 111IF11 111111�� 111111 111111111111 1p�111 1111111 1
111 11 11 �M�i �
wntten consent.
snau am e me Tiltit to Exc7ciso any WTHU M1111I LL
i d without any further demand or notice.
............
of this Agreement without prejudice to any other right or remedy City may have under this
f *r
for Work properly performed prior to the effective date of termination.
11 D21115 rM I DI
19.1 Any delay or failure of either party in the performance of its required obligatior"
hereunder shall be excused if and to the extent caused by acts of God; fire; flood; windsto
explosion; riot; war; sabotage; strikes; extraordinary breakdown of or damage to City's affiliate
lsJ�-6 %,-u ant, *r fg-cifities;-u,
r
v
tI
e
a. .........
of the parties hereunto shall be diligent in attempting to remove such cause or causes. If Ja
circumstance of Force Majeure remains in effect for sixty days, either party may terminate th
Agreement.
Ni This Agreement is made and shall be interpreted, construed, governed, and enforced
in accordance with the laws of the State of Florida. Venue for any state action or litigation shall be
Brevard County, Florida. Venue for any federal action or litigation shall be Orlando, Florida.
21.1 Paragraph headings are for the convenience of the parties only and are not to
construed as part of this Agreement.
City of Cape Canaveral GLE Associates, Inc.
22.1 In the event any portion or part of thereof this Agreement is deemed invalid, against
public policy, void, or otherwise unenforceable by a court of law, the parties shall negotiate an
equitable adjustment in the affected provision of this Agreement. The validity and enforceability of
the remaining parts of this Agreement shall otherwise by fully enforceable.
23.1 IT'aiver by either party of any terms, or pro -vision of this Agreement shiit not
considered a waiver of that term, conon, or provision in the future. I
1 11 MA ! a 1k
24.1 Nothing in this Agreement shall be construed to give any rights or benefits to anyone
other than City and Consultant.
K -MMU -IM I I I ft # I IWOM
26.1 This Agreement, including any Task Orders and Schedules, Attachments, Appendilm
and Exhibits attached hereto, constitute the entire agreement between City and Consultant wi
resrscect to the Services s(tecified and all gevious reGiresentations relative thereto- either written
N ral, are hereby annulled and superseded.
27.1 Nothing herein shall be deemed to create a joint venture or principal-agelD
relationshi between the artim and neither iartv is authorized to nor shall either jarti act towaff
0110 1 M10 11 11M milli I uwx�zrg gagulmll 1=141ow lugg I
2
6ity of Cape Canaveral � GLE Associates, Inc.
12
28.1 Should either party bring an action to enforce any of the terms of this Agreement,
-f Ar" 11'4r
J
29.1 This Agreement may be executed in any number of counterparts, each of which when
so executed and delivered shall be considered an original agreement; but such counterparts shall
together constitute but one and the same instrument.
30.1 City and Consultant each represent that they have both shared equally in drafting this
Agreement and no party shall be favored or
in the event of a dispute between the parties.
31.1 Any notices required to be given by the terms of this Agreement shall be delivered
hand or mailed, postage prepaid to: I
InZWOTIM
GLE Associates, Inc.
Anna Kucenic
1320 N. SernomxAU-��RjAki�2ffl
Orlando, FL 32807
(407) 658-4151 Phone
(407) 658-4410 Fax
Emfiw
City of Cape Canaveral
Attention: City Manager
105 Polk Avenue
(321) 868-1230 Phone
(321) 868-1224 Fax
Eity of Cape Canaveral GIB Associates, Inc,
13
31.2 Either party may change the notice address by providing the other party written notice
of the change.
32.0 SOVERE IGN IMMUNITY
32.1 Notwithstanding any other provision set forth in this Agreement, nothing contained in
this Agreement shall be construed as a waiver of the City's right to sovereign immunity under
section 768 .28, Florida Statutes, or other limitations imposed on the City's potential liability under
state or federal law. As such, the City shall not be liable under this Agreement for punitive damages
or interest for the period before judgment. Further, the City shall not be liable for any claim or
judgment, or portion thereof, to any one person for more than one hundred thousand dollars
($ 100, 000.00), or any claim or judgment, or portion thereof, which, when totaled with all other
claims or judgments paid by the State or its agencies and subdivisions arising out of the same
incident or occurrence, exceeds the sum of two hundred thousand dollars ($200,000.00). This
paragraph shall survive termination of this Agreement.
15 x FI&KOOR111
MMO=] Ili M�M
a. Consultant is duty registered and licensed to do business in the State of Florida and is
in good standing under the laws of Florida, and is duly qualified and authorized to carry on the
�,`unctions and operations set forth in this Agreement.
b. The undersigned representative of Consultant has the power, authority, and legal right
to execute and deliver this Agreement on behalf of Consultant.
34.1 Consultant shall indemnify and hold harmless the City, and its officers (including its
City Attorneys) and employees, from liabilities, damages, losses, and costs, including, but not
limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness, or
34.2 Consultant shall also indemnify and hold harmless the City, and its officers (including
fts CAY Attorne�s) and emUlo)
.Lees, from liabilities, damages. losses. and costs, includi but not
11 1 AIR I
P;tv r%f Cnte-Orivve-rnl GLF 1,�.q*vintpq- Ive-
The indemnity provisions set forth in Paragraphs 34.1 and 34.2 shall be considered separate
and independent indemnity provisions.
35.1 The presence or duties of Consultant's personnel at a construction site, whether as
onsite representatives or otherwise, do not make Consultant or Consultant's personnel in arty way
and do not relieve the construction contractors or ankp�-��, 4 -
responsibilities, including, but not limited to, all construction methods, means, techniques,
eguence
work in accordance with the applicable construction contract documents and any health or safety
precautions required by such construction work. Consultant and Consultant's personnel. have no
aytl*rity to-cx=i6cany control cm-,T-any-(,*nstrxction c*ntract*r or oVier ent* or ehi-,ir
35.2 The presence of Consultant's personnel at a construction site is for the purpose of
yx,ovidin
the applicable contract documents and that the integrity of the design concept as reflected in the
contract documents has been implemented and preserved by the construction contractor(s).
Consultant neither guarantees the performance of the construction contractor(s) nor assumes
responsibility for construction contractor's failure to perform work in accordance with the contract
documents. For this Agreement ordy, construction sites include places of manufacture for materials
incorporated into the construction work, and construction contractors include manufacturers of
materials incorporated into the construction work.
36.1 Record drawings, if required, will be prepared, in part, on the basis of informati
co
components, or exact manner in which the project was finally constructed. Consultant is n
record drawings.
a. No principal (which includes officers, directors, or executive) or individual holding a
professional license and oerforming work under this AL-reement is nresentIv debarred. susngetmIx
UM
City of Cape Canaveral GLE Associates, Inc.
15
proposed for debarment, declared ineligible or voluntarily excluded from participation in any
architectural activity by arty Federal, State, or local governmental commission, department,
corporation, subdivision, or agency;
b. No principal (which includes officers, directors, or executive) or individual holding a
ii :, i ii I I
liw 1611 e-av&ii ! 15c) TL cas e --u TV] it'ved *,i
the employee or officer's official action or judgment.
of the Agreement.
IN WITNESS WHEREOF, the parfies hereto caused this Agreement to be executed by their
duly authorized representatives as of the date first written above.
David Greene, City Manager
B"Hylu
Robert B. Greene, Presiden
I *
City of Cape Canaveral / GLE Associates,be.
16
11301IRM
Fee Schedule
Architectural Fees
I. Principal Architect, RA $150.00/hour
2. Senior Project Architect, RA $125.00/hour
3. Project Architect, Project Manager $105.00/hour
4. Senior Designer/Draftsman $75.00/hour
5. Staff Designer/Draftsman $65.00/hour
6. Clerical $55.00/hour
Mechanicy l/E Nectrical/Civil E mineeri
tUx��ees�
1. Principal Engineer, PE $150.00/hour
2. Senior Project Engineer, PE $125.00/hour
3. Project Engineer, PE, Project Manager
tp $105.00/hour
4. Staff Engineer, El $90.00/hour
5. Senior Designer/Draftsman $75.00/hour
6. Staff Designer/Draftsman $65.00/hour.
7. Clerical $55.00/hoiLtr
4300 W. D ress Street' Suite 400
Orlando I Ft. Lauderdale I Miami I Jacksonville I Gainesville I Atlanta I Houston I Nashvilie
ArchiteGture AA 0002369 - Engineer EB 0006483 - Asbestos ZA 0000034 - Geology 0000297 - Surveying L87679
ACORQ AGENCY CUSTOMER ID: 00040378
LOC'N:
ADDITIONAL REMARKS SCHEDULE Page Of
AGENCY NAMED INSURF0
Lassiter-Wre Insurance GLE Associates, Inc.
POUCYNUMBER Suite 400
Ta ,
CA ER MAIC CCOE 7 rrpaFL 33607
EFMCMVE DATE:
A-D-DITI -AL REMARKS
The ACORD name and logo are registered marks of ACCORD
a *2 1 M U4141 � 1 M -4 b 4a MCT- 1A
ADDITIONAL INSURED - OWNERS, LESSEES OR
CONTRACTORS - SCHEDULED PERSON OR
ORGANIZATION
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name Of Additional Insured PersonW
f)r Orna , - , ,. Locations Coere esti ns
Any person or organization with who the Named Insured Where specified by written contract,
enters into a written contract that requires them to be
named as an Additional Insured and the contract is
executed prior to the start of the project.
guired to.complete this Schedule. If not shown above, will be shown in the DeclarallonsE=
A. Section 11 - Who Is An Insured is amended to
include as an additional insured the person(s) or
organization(s) shown in the Schedule, but only with
respect to liability for 'bodily injury". "property
damage' or "personal and advertising injury"
caused. in whole or in part. by:
1. Your acts or omissions; or
2. The acts or omissions of those acting an your
behalf:
in the performance of your ongoing operations for
the additional insured(s) at the location(s)
designated above.
S. With respect to the insurance afforded to these
additional insureds, the following additional
exclusions apply:
This insurance does not apply to "bodily injury" or
.. property damage" occurring after:
1All work. including mateCials. parts or equipment
furnished in connection with such work, on the
project (other than service, maintenance or
repairs) to be performed by or on behalf of the
additional insured(s) at the location of the
covered operations has been completed; or
k. That portion of "your work" out of which the
injury or damage arises has been put to its
intended use by any person or organization
other than another contractor or subcontractor
engaged in performing operations for a principal
as a part of the same project.
CG 20 10 17 04 0 ISO Properties, Inc., 2004 Page I of 1 0