Loading...
HomeMy WebLinkAboutJAR Construction, Inc. South Ditch Improvements Project I 1 i , City of Cape Canaveral South Ditch Improvements Project Brevard County, Florida i CONSTRUCTION CONTRACT THIS CONTRACT, made and entered into this B day of May e - , 2011, A.D., by and between the City of Cape Canaveral, party of the first part (hereinafter sometimes called the "Owner "), and JAR Construction, Inc., party of the second part (hereinafter sometimes called the "Contractor "). WITNESSETH: That the parties hereto, for the consideration hereinafter set forth, mutually agree as follows: 1.01 SCOPE OF THE WORK The contractor shall furnish all labor, materials, equipment, machinery, tools, apparatus, and transportation and perform all of the work shown on the Drawings and described in the Specifications entitled, Specifications for City of Cape Canaveral South Ditch Improvements Project, City of Cape Canaveral, SSA Job No. 06 -0018 as prepared by Stottler Stagg & Associates, Architects, Engineers, Planners, Inc., and described in the Contract Documents and shall do everything required by this Contract and the other Contract Documents. 1.02 THE CONTRACT SUM A. The Owner shall pay to the Contractor for the faithful performance of the Contract, in lawful money of the United States, and subject to additions and deductions as provided in the Contract Documents, as follows in 1.02B. B. Based upon the price shown in the Proposal for City of Cape Canaveral South Ditch Improvements Project heretofore submitted to the Owner by the Contractor, a copy of said Proposal being a part of these Contract Documents, the aggregate amount of this Contract is the sum of Ninety -five Thousand, One - hundred Fifteen Dollars and Thirty Cents ($95,115.30). 1.03 COMMENCEMENT AND COMPLETION OF WORK A. The Contractor shall commence work within 30 calendar days after the start of the Contract Time identified on the Notice to Proceed. B. The Contractor shall prosecute the work with faithfulness and diligence and shall complete the work no later than 120 calendar days after receipt of the Notice to Proceed. 1 1.04 CONTRACTOR'S ACCEPTANCE OF CONDITIONS A. The Contractor hereby represents that he has carefully examined the surface of the site and made sufficient inquiry and reasonable subsurface and other investigations to become fully satisfied that such site is a correct and suitable one for this work and the Bidder assumes full 1 i 1 1 City of Cape Canaveral South Ditch Improvements Project Brevard County, Florida responsibility therefore. The provisions of the Executed Contract Document shall control any inconsistent provisions contained in the Technical Specifications. All Drawings and Technical Specifications have been read and carefully considered by the Contractor, who understands the same and agrees to their sufficiency for the work to be done. It is expressly agreed that under no circumstances, conditions or situations shall this Contract be more strongly construed against the Owner than against the Contractor and his Surety, or the Engineer. B. Any ambiguity or uncertainty in the Drawings or Technical Specifications shall be interpreted and construed by the Owner's Engineer and his decision shall be final and binding upon all parties. C. It is distinctly understood and agreed that the passing, approval and /or acceptance of any part of the work or material by the Owner, his Engineer or by any agent or representative as being in compliance with the terms of this Contract or with the Drawings, and Technical Specifications covering said work, shall not operate as a waiver by the Owner of strict compliance with the terms of this contract or the Drawings and Technical Specifications covering said work; and that the Owner may require the Contractor and his Surety to strictly comply with this Contract and the Drawings and Technical Specifications; and that the Owner may require the Contractor and the Surety to repair, replace and restore any and all of said work and materials which within a period of one year from and after the date of the acceptance of the work are found to be defective or to fail in any way to comply with this Contract or with the Drawings and Technical Specifications. This provision shall not apply to materials or equipment which has been subjected to normal wear and tear. The Contractor shall not be required to do normal maintenance work under the guarantee provisions. Failure on the part of the Contractor or his Surety, immediately after Notice to either, to repair or replace any such defective materials and workmanship shall entitle the Owner, if the Owner sees fit, to replace or repair the same and recover the reasonable cost of such replacement or repair from the Contractor and his surety, who shall in any event be jointly and severally 1 liable to the Owner for all damage, loss and expense caused to the Owner by reason of the Contractor's breach of this Contract or his failure to comply strictly and in all things with this Contract and with the Drawings and Technical Specifications. 1.05 LIQUIDATED DAMAGES A. It is mutually agreed that time is of the essence in performance of this Contract and should ■ the Contractor fail to complete the work within the specified time, which would include any appropriately authorized extensions thereof, there shall be deducted from the compensation otherwise to be paid to the Contractor, and the Owner will retain the amount of Fifty Dollars ($50) per calendar day as fixed, agreed, and liquidated damages for each calendar day elapsing beyond the specified time for completion or any authorized extension thereof, which sum shall represent the actual damages which the Owner will have sustained by failure of the Contractor to complete the work within the specified time; it being further agreed that said sum is not a penalty, but is the stipulated amount of damages sustained by the Owner in the event of such default by the Contractor. 2 i 1 City of Cape Canaveral South Ditch Improvements Project Brevard County, Florida 1.06 PARTIAL AND FINAL PAYMENTS In accordance with the provisions fully set forth in the General Conditions, and subject to additions and deductions as provided, the Owner shall pay the Contractor as follows: 1 I A. Within forty -five (45) days after receipt of the Contractor's request for partial payment by the Owner, the Owner shall make partial payments to the Contractor, on the basis of the estimate of work as approved by the Owner's Engineer, pursuant to provisions of Section 219.70, Florida Statutes, Florida Prompt Payment Act, Tess ten percent (10 %) of the amount of such estimate which is to be retained by the Owner until all work has been performed strictly in accordance with this Contract and until such work has been accepted by the Owner. B. Owner may require submission by the Contractor of evidence satisfactory to the Owner that all payrolls, material bills and other costs incurred by the Contractor in connection with the construction of the work have been paid in full, and also, after all guarantees that may be required in the Technical Specifications have been furnished and are found acceptable by the Owner, final payment on account of this Contract shall be made within forty -five (45) days after completion by the Contractor of all work covered by this Contract and acceptance of such work by the Owner. C. Upon receipt of written notice from the Contractor that the work is ready for final inspection and acceptance, the Owner shall, within ten (10) days, make an inspection thereof. If the Owner finds the work acceptable under the Contract and the Contract is fully performed, the Public Works Director, or designee, shall present the final request for payment to the City of Cape Canaveral for approval, stating that the work required by the Contract has been completed and is acceptable under the terms and conditions thereof. D. Before the final request for payment is submitted to the City of Cape Canaveral, the Contractor shall deliver to the Public Works Director, or designee, a complete release of all liens arising out of this Contract, or receipts in full in lieu thereof, and an Affidavit certifying that all suppliers and subcontractors have been paid in full and that all other indebtedness connected with the work has been paid, and a consent of the surety to final payment. i E. The making and acceptance of the final payment shall constitute a waiver of all claims by the Owner, other than those arising from faulty or defective work, failure of the work to comply with requirements of the Contract Documents or terms of any special warranties required by the Contract Documents. It shall also constitute a waiver of all claims by the Contractor, except those previously made in writing and identified by the Contractor as unsettled at the time of the final application for payment. 1.07 ADDITIONAL BOND It is further mutually agreed between the parties hereto that if, at any time after the execution of this Contract and the Performance and Payment Bonds hereto attached for its faithful performance, the Owner shall deem the surety or sureties upon such bonds to be unsatisfactory, or if, for any reason, such bond(s) ceases to be adequate to cover the performance of the Work, the Contractor shall, at his expense, and within three days after the receipt of Notice from the Owner to do so, furnish an additional bond or bonds, in such form and amount, and with such sureties as shall be satisfactory 3 City of Cape Canaveral South Ditch Improvements Project Brevard County, Florida to the Owner. In such event, no further payment to the Contractor shall be deemed due under this Contract until such new or additional security for the faithful performance of the work shall be furnished in manner and form satisfactory to the Owner. 1.08 CONTRACT DOCUMENTS A. The Contract Documents, as stated in the Instructions to Bidders and attached hereto, are as fully a part of this Contract as if herein repeated. B. Where there is a conflict between an Owner requirement set forth in the Contract Documents, and a more stringent state or Federal requirement which is set forth in the General Conditions section, the more stringent state or Federal requirement shall prevail. IN WITNESS WHEREOF the parties hereto have executed this Contract on the day and date first above written in five (5) counterparts, each of which shall, without proof or accounting for the other counterparts, be deemed an original Contract.* Attest: City of Cape Canaveral are. II/V_ applA9 By Clerk • Seal Title: C ct 1.01/4 Signed, Sealed and Witnessed in the presence of: ** Party of the Second Part By: / Title: V / PJZERDEA 7 (Seal) r (Seal) ( *) In the event that the Contractor is a Corporation, there shall be attached to the Contract a certified copy of a resolution of the Board of Directors of the Corporation, authorizing the officer who signs the Contract to do so in its behalf. ( * *) Two witnesses are required when Contractor is a sole ownership or partnership. 4 i City of Cape Canaveral South Ditch Improvements Project Brevard County, Florida CERTIFICATE STATE OF FLORIDA ) ss COUNTY OF BREVARD ) I HEREBY CERTIFY that a meeting of the Board of Directors of J Art- C6►JSfeachoi v%NG- a corporation under the laws of the State of fL5 Z4 0 A- , held on 2125 , 20 (1 , the following resolution was duly passed and adopted: Vtt' "RESOLVED, that 1 LAP C , 6: 16(24)P3 , a,President of the corporation, be and he is hereby authorized to execute the Contract dated Fe6r1A.4101 ZS , 20 11 , between the CITY OF CAPE CANAVERAL, and this corporation, and that his execution thereof, attested by the Secretary of the corporation and with corporate seal affixed, shall be the official act and deed of this corporation." I further certify that said resolution is now in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the official seal of the corporation this 2-5 day of . V- el6YLAAw► , 20 I I Secretary ( 6 ( ore/ 1 " di- 5 Attachment #1 Payment and Performance Bonds 620 N. Wymore Road, Suite 200 FLORIDA SURETY BONDS, INC• 407 - 786 -7770 Fax 407 - 786 -7766 1326 S. Ridgewood Avenue, Suite #15 Daytona Beach, FL 32114 386 - 898 -0507 Fax 386 - 898 -0510 888 - 786 -BOND (2663) Fax 888 - 718 -BOND (2663) March 16, 2011 www. F I or i daS u rety B onds. com City of Cape Canaveral P.O. Box 326 Cape Canaveral, FL 32920 Re: Authority to Date Bonds and Powers of Attorney Principal: JAR Construction, Inc. Bond No.: 1000884736 Project: SSA Job No. 06 -0018, City of Cape Canaveral South Ditch Improvements Project (replacement of headwall and regrading of existing pond), West Central Blvd., Cape Canaveral, FL Dear Sir or Madam: Please be advised that as Surety on the above referenced bond, executed on your behalf for this project, we hereby authorize you to date the bonds and the powers of attorney concurrent with the date of the contract agreement. Once dated, please fax a copy of the bonds to our office. Sincerely, American Contractors Indemnity Company Q 3c204‘. .. gza d "....10 Gloria A. Richards Attorney -in -Fact and Florida Licensed Resident Agent I THE AMERICAN INSTITUTE OF ARCHITECTS Bond No.: 1000884736 Executed in 2 Counterpart (s) AIA Document A311 Performance Bond KNOW ALL MEN BY THESE PRESENTS: that JAR Construction, Inc. (Here insert full name and address or legal title of Contractor) 518 Tivoli Court Altamonte Springs, FL 32701 (407) 462 -8989 as Principal, hereinafter called Contractor, and, American Contractors Indemnity Company 601 South Figueroa St., 16th Floor (Here insert full name and address or legal title of Surety) Los Angeles, CA 90017 (310) 649 -0990 as Surety, hereinafter called Surety, are held and firmly bound unto p (� a Ci ier insert iuli name or legal title of Owner) P.O. Box 326 Cape Canaveral, FL 32920 (321) 868 -1230 as Obligee, hereinafter called Owner, in the amount of Ninety-Five Thousand One Hundred Fifteen and 30/100 Dollars ($ 95,115.30 ), for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated \\A.AQca. Z g 24, L7 , entered into a contract with Owner for (Here insert full name and address and description of project) SSA Job No. 06 -0018 City of Cape Canaveral South Ditch Improvements Project (replacement of headwall and regrading of existing pond), West Central Blvd., Cape Canaveral, FL in accordance with Drawings and Specifications prepared by Stottler Stagg & Associates, Architects, Engineers, Planners, Inc. (Here insert full name and address or legal title of Architect) which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND. • AIA ® 1 FEBRUARY 1970 ED. • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE. N.W., WASHINGTON. D.C. 20006 ORICIq ;arty ' A ds INC. PERFORMANCE BOND NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall promptly and faithfully perform said Contract, then this obligation shall be null and void; otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or defaults under the contract or contracts of completion extension of time made by the Owner. arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; Whenever Contractor shall be, and declared by Owner but not exceeding, including other costs and damages to be in default under the Contract, the Owner having performed for which the Surety may be liable hereunder, the amount Owner's obligations thereunder, the Surety set forth in the first paragraph hereof. The term "balance may promptly remedy the default, or shall promptly of the contract price," as used in this paragraph, shall mean the total amount payable by Owner to Contractor 1) Complete the Contract in accordance with its terms under the Contract and any amendments thereto, less and conditions, or the amount properly paid by Owner to Contractor. 2) Obtain a bid or bids for completing the Contract in Any suit under this bond must be instituted before accordance with its terms and conditions, and upon de- the expiration of two (2) years from the date on which termination by Surety of the lowest responsible bidder, final payment under the Contract falls due. or, if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible No right of action shall accrue on this bond to or for bidder, arrange for a contract between such bidder and Owner, the use of any person or corporation other than the and make available as Work progresses (even Owner named herein or the heirs, executors, adminis- though there should be a default or a succession of trators or successors of the Owner. THIS BOND IS GIVEN TO COMPLY WITH SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES, AND ANY ACTION INSTITUTED BY A CLAIMANT UNDER THIS BOND FOR PAYMENT MUST BE IN ACCORDANCE WITH THE NOTICE AND TIME LIMITATION PROVISIONS IN SECTION 255.05(2) OR SECTION 713.23 FLORIDA STATUTES. Signed and sealed this day of )AR Construction, Inc. (Principal) (Seal) • 61/1;14,i) at414.0) (Witness) (Title) AmPriran Contractors Indemnity Company (Surety) (Seal) (Witn '°•-■ a • QE . C_Pla ta - Gloria A. Richards Attorney -in -Fact and FL Lic. Resident Agent Inquiries: (407) 786 -7770 AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND. • AIA ® 2 FEBRUARY 1970 ED. • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE.. N.W., WASHINGTON, D.C. 20006 i THE AMERICAN INSTITUTE OF ARCHITECTS 4111ilip Bond No.: 1000884736 Executed in 2Counterpart (s) AIA Document A311 Labor and Material Payment Bond THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND IN FAVOR OF THE OWNER CONDITIONED ON THE FULL AND FAITHFUL PERFORMANCE OF THE CONTRACT KNOW ALL MEN BY THESE PRESENTS: that JAR Construction, Inc. 518 Tivoli Court (Here insert full name and address or legal title of Contractor) Altamonte Springs, FL 32701 (407) 462 -8989 as Principal, hereinafter called Principal, and,American Contractors Indemnity Company 601 South Figueroa St., 16th Floor (Here insert full name and address or legal title of Surety) Los Angeles, CA 90017 (310) 649 -0990 as Surety, hereinafter called Surety, are held and firmly bound unto City of Cape Canaveral (Here insert full name and address or legal title of Owner) P.O. Box 326 Cape Canaveral, FL 32920 (321) 868 -1230 as Obligee, hereinafter called Owner, for the use and benefit of claimants as herein below defined, in the amount of Ninety -Five Thousand One Hundred Fifteen and 30/100 (Here insert a sum equal to at least one -half of the contract price) Dollars ($ 95,115.30 ). for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has by written agreement dated 1 4 " \Mac ∎+ z a , 2,0 , , entered into a contract with Owner for (Here insert full name and address and description of project) SSA Job No. 06-0018 City of Cape Canaveral South Ditch Improvements Project (replacement of headwall and regrading of existing pond), West Central Blvd., Cape Canaveral, FL in accordance with Drawings and Specifications prepared by Stottler Stagg & Associates, Architects, Engineers, Planners, Inc. (Here insert full name and address or legal title of Architect) which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND. • AIA ® 3 FEBRUARY 1970 ED. • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 20006 �oRidA 1 13oNds INC. LABOR AND MATERIAL PAYMENT BOND NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make payment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject, however, to the fol- lowing conditions: 1. A claimant is defined as one having a direct con- accuracy the amount claimed and the name of the party tract with the Principal or with a Subcontractor of the to whom the materials were furnished, or for whom Principal for labor, material, or both, used or reasonably the work or labor was done or performed. Such notice required for use in the performance of the Contract, shall be served by mailing the same by registered mail or labor and material being construed to include that part of certified mail, postage prepaid, in an envelope ad- water, gas, power, light, heat, oil gasoline, telephone dressed to the Principal, Owner or Surety, at any place service or rental of equipment directly applicable to the where an office is regularly maintained for the trans - Contract. action of business, or served in any manner in which legal process may be served in the state in which the 2. The above named Principal and Surety hereby aforesaid project is located, save that such service need jointly and severally agree with the Owner that every not be made by a public officer. claimant as herein defined, who has not been paid in full before the expiration of a period of ninety (90) b) After the expiration of one (1) year following the days after the date on which the last of such claimant's date on which Principal ceased Work on said Contract, work or labor was done or performed, or materials were it being understood, however, that if any limitation em- fumished by such claimant, may sue on this bond for bodied in this bond is prohibited by any law controlling the use of such claimant, prosecute the suit to final the construction hereof such limitation shall be deemed judgment for such sum or sums as may be justly due to be amended so as to be equal to the minimum period claimant, and have execution thereon. The Owner shall of limitation permitted by such law. not be liable for the payment of any costs or expenses of any such suit. c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the Project, or any part thereof, is 3. No suit or action shall be commenced hereunder by situated, or in the United States District Court for the any claimant: district in which the Project, or any part thereof, is sit- uated, and not elsewhere. a) Unless claimant, other than one having a direct contract with the Principal, shall have given written 4. The amount of this bond shall be reduced by and to notice to any two of the following: The Principal, the the extent of any payment or payments made in good Owner, or the surety above named, within ninety (90) faith hereunder, inclusive of the payment by Surety of days after such claimant did or performed the last of the mechanics' liens which may be filed of record against work or labor, or furnished the last of the materials for said improvement, whether or not claim for the amount which said claim is made, stating with substantial of such lien be presented under and against this bond. THIS BOND IS GIVEN TO COMPLY WITH SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES, AND ANY ACTION INSTITUTED BY A CLAIMANT UNDER THIS BOND FOR PAYMENT MUST BE IN ACCORDANCE WITH THE NOTICE AND TIME LIMITATION PROVISIONS IN SECTION 255.05(2) OR SECTION 713.23 FLORIDA STATUTES. Signed and sealed this day of JAR Construction, Inc. (Principal) (Seal) (W (Witness) at'ii PA blid- (Title) American Contractors Indemnity Company (Surety) (Seal) � i tness ) �r _•� �'�i g ■ _ �. ,' ti Gloria A. Richar•s Attorney -in- Factand FL Lic, Resident Agent Inquiries: (407) 786 -7770 AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND. • AIA ® 4 FEBRUARY 1970 ED. • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE,, N.W., WASHINGTON, D.C. 20006 _ - - • , . _ 111 I i I OWER OF ATTORNEY __ __ = _ _1 , — AMERICAN CONTRACTORS INDE Y T COMPANY UNITED STATES SUIZETWOMPAIVY U.S. SPECIALTY INSUR KNOW ALL MEN BY THESE PRESENTS: That American Contractors Indemnity Company, a California corporation, United States Surety Compan, a Maryland corporation and U.S. Specialty Insurance Company, a Texas corporation (collectively, the wli y these presents maken -Altnill),WlpmsWite-antappoint: , ,111 II II lh = -= ffYi nkr. Thdch, Susan L. 10 - CitNi_reitiry MacKenzie, Don DO „__ tome, Teresa .I Durham, Les11.Mow GlorleWutiWa LAlaughter or Cheryl 110o1Or of Maitland, 1odda -- ---- -- - its true and lawful Attomey(s)-in-fact, each in their separate capacity if more than one is named above, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings _ orAithestrtnts or contracts of suretyship include riders, amendmentsoLmt commits of surety, providing tbordmn ==-__.elmdtloinu mrffnceed 4 , 1 , 1' ,' ****Three million***** = - _ -- == D (s_.1mowrior == --= M ---- = ---- ttmney shall expi l yi, , hithout NO I rl 'lotion on September7,1_DM n_i—sMnsvrW Attorney is ganW mieniTte. — , _ - - -ttitWirity t1 `th following resolutionithidopted by the boards of Directors orftro - - • — Be it Resolved, that the President, any Vice-President, any Assistant Vice-President, any Secretary or any Assistant Secretary shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attomey(s)-in-Fact to represent and act for and on behalf of the Company subject to the following provisions: , 1 - triite given full power atitItotity fi!saltil in titame of and on behalf of the pany, to exeCut I and cle r 1 - IchetWeld -r _---- - - - ._- 2 ritztes3itTnicfzr_agreements or indatuto ccoMtWnit obligatory undertaking sl 'att tiny and all neti and documents c"cimritatit A3Dtiggetthen and any s. ilinitimtc_Wid W-tiny such Attomey-in-Fta1l be binding tipl the Company - asIMsiMIWAI -=:.- , I 1 -- ==ni:Wealed W by the Corporate SeerMw -- -- - - Be it Resolved that the signature of any authorized officer and seal of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signature or facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached. •MriThi - M -- WaREOF, The Coptilanies have cOsed this instrument to besigrt$ ani seals to be-tMgrwzed;tht--- i -r= Mm).011. - - - - -- -- 1 1 z AMERICAN CONTRACTORS INDEMNITY COMPANY UNITED STATES SURETY COMPANY U.S. SPECIALTY INSURANCE COMPANY 400 , 4 Corpora .4,:=',:1-4; Corporate Seals k, _ _ 7 Nob. § munirm -=- k- = -,_._._ irai ma By: , 1 i , ..= --:-:—. ---,:- .11i '7.. = - - - - 4= - ., Dan ';.1 P. Aguilarl I I', l' ce Pr sident ----------- ---- — ----- ==_ 1 i l 1 = ol=l2aAWnia . --P`= -,' - '-_- ._ :i i -- ------------= = - County of Los Angeles SS: On this 41h dayAiJanuary, 2011, before me, JenruTer Ceron, a notary public, personallmpeand Daniel P. Aguilar, Vice President of _ _ . nars Indemnity C repany, Unite 1 tates Surety Company -AW1 - U. Splturance CompanlOoNc, _=._ R-Me=i.si - tMtctory evideRe I te be the p� r4 L Whose name is subsette,,Thimitrinmstmnent and ackm:avW1W txutiezU == 1 in his authori er1 capacity, a&1 that by his signature orrft tUtnin ft person(s), or the 11041 1 k W f ff - which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. , _ WITNEnAny 1:1 and official seal._ AMMER CERON =SION # I --, Si = twv_ =_=__ -___ _ 61 - -= Oe. 1' A, l l 11 Peelle - CsiNt =____: _ _ Lot Anion c, , ,: 1 - - - - 1 -- - - ---,----- ---.- MI COMM* atkill Set 2/. 2013 I, Jeannie J. Kim, Assistant Secretary of American Contractors Indemnity Company, United States Surety Company and U.S. Specialty Insurance Company, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, =_-extinItompanies, whic l i still in full I force and effect; furtherri,Wie 171:NAtiottrof the Boards of Etimbars, alen&iir 1H == - Ai'Manr Imz'i t 'my are in full fe e and effect. J 1 _ _ in Witness Whereof, I have hereuntO set my hand and affixed the seals of stM=Cbritpanies at Los Angeles, Californkttlris — day of I — _ - - -, _ - 1,11 oNt Ulthci- ar: I s A 4 ii_— -=.-_ — - i'' ' J 11 h 4 ,4% III h 1 i "ilh ■ lip ____ -- - -- .., p 0M NOjeCCR$4 11111. ' - =I ,; SEAL - tai 4. Jeannie J. Kim, AssistantWrMry :. get24,11911 .... . mr „ Agency No. 11520 V 4 ,.', p