Loading...
HomeMy WebLinkAboutcocc_dwzinser_7404_n_atlantic_demo_agreement_20220517City ofCape Canaveral 74U4N.Atlantic Avenue Property Demolition AGREEMENT �� �is��ene�m�g�s*~ day of '2022 between the CITY 0F CAPE aFlorida municipal corporation (herein referred to as CITY) and O.W.Zinser Company, aState Certified Contractor authorized and duly licensed to do business in the State ofFlorida (herein referred to as [ONTRACTO0,asfollows: 1 DESCRIPTION OF WO�KK- CONTRACTOR shall perform the work, inaccordance with the Contract Documents, for demolition work as set forth in Exhibit A - Scope of Services,attached hereto as Exhibit "A", and fully incorporated by this reference ("work"). Z CONTRACT DOCUMENTS - The Contract Documents consist ofthis Agreement; Bid #2022-01; Documents issued by the CITY, CONTRACTOR'S Bid Submittal; and all Change Orders approved by the CITY after execution of this Agreement. These Contract Documents are hereby incorporated into this Contract bythis reference. ORDER OF PRECEDENCE - In case of any inconsistency in any of the documents bearing on the Agreement between the CITY and the CONTRACTOR, the inconsistency shall be resolved by giving precedence in the following order: a. Agreement Exhibit and b. CONTRACTOR'S Bid Submittal; c Change Orders; Any inconsistency in the vvO[k description shall be [|8hfi8d by the CITY and performed by the CONTRACTOR. 4. AGREEMENT U -At its discretion, during the course of the work, should any errors, ambiguities or discrepancies be found in the Agreement or specifications, the CITY atits sole discretion will interpret the intent of the Agreement and work descriptions and the CONTRACTOR hereby agrees toabide h«the C|TY'sinterpretation and agrees tocarry out the work in accordance with the decision of the CITY. When the material, article or equipment is designated by o brand name and more than one brand name is listed, it will be understood that the work is based on one brand name only. The CONTRACTOR will be responsible for all coordination necessary to accommodate the material, article or equipment being provided without additional cost to the CITY. A substitute material, article or equipment is allowed if it is reasonably equivalent tothe brand name specified. The CITY has full discretion to decide whether asubstitute isreasonably equivalent. CONTRACTOR must notify the CITY prior touse of the substitute for a specified brand name and allow the CITY to make a determination before CONTRACTOR uses the substitute. AGREEMENT City ofCape Canaveral 74U4N.Atlantic AvenuaPropmrtyDemoldion 5. CONTRACT TIME - The CONTRACTOR shall begin work within thirty <30 days after the issuance of written Notice to Proceed and shall complete the work within forty-five (45) calendar days. Extensions, if any, are authorized by CITY, and may only be granted in writing. 6 -[ITYondCONTRACTOR recognize that time isof the essence of this Agreement and that CITY will suffer financial loss ifthe work isnot substantially complete within the time specified in Paragraph S above plus any extensions thereof allowed in accordance with the General Conditions. They also recognize the delays, expense and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by CITY if the work is not substantially completed on time. Accordingly, instead of requiring any such proof, CITY and CONTRACTOR agree that asliquidated damages for delay (but not asa penalty) CONTRACTOR shall pay CITY one hundred dollars ($1D0.00) per day for each day that expires after the time specified in Paragraph 5 for final completion until the work is finally complete, and that CITY has paid toCONTRACTOR the consideration often ($10.00)dollars as consideration for this provision. 7. CONTRACT PRICE, LUMP SUM CONTRACT -The[DYviUpay the CONTRACTOR incurrent funds for the performance of the work, subject to additions and deductions by Change Order, the Total Contract Price of thirty four thousand, nine hundred dollars and no cents ($34,900.00). 8, TERMINATION -TheOTYeservesthe right to revoke and terminate this Agreement and rescind all rights and privileges associated with this Agreement, without penalty, for convenience. Further, the CITY reserves the right to revoke and terminate this Agreement in the following circumstances, each of which shall represent adefault and breach mfthis Agreement: a. CONTRACTOR defaults in the performance ofany material covenant orcondition of this Agreement and does not cure such other default within seven Cq calendar days after written notice from the CITY specifying the default complained of unless however, the nature of the default is such that it cannot, in the exercise of reasonable diligence, be remedied within seven (7) calendar days, in which case the CONTRACTOR shall have such time as is reasonably necessary to remedy the default, provided the CONTRACTOR promptly takes and diligently pursues such actions as are necessary therefore; or b CONTRACTOR isadjudicated bankrupt ormakes any assignment for the benefit of creditors or CONTRACTOR becomes insolvent, or is unable or unwilling to pay its debts; or c CONTRACTOR has acted negligently, as defined bygeneral and applicable law, in performing the work hereunder; V[ d. CONTRACTOR has committed any act nffraud upon the CITY, or e. CONTRACTOR has made a material misrepresentation of fact to the CITY while performing its obligations under this Agreement; Or AGREEMENT City of Cape Canaveral 7404N.Atlantic Avenue Property Demolition [ CONTRACTOR is experiencing a labor dispute, which threatens to have a substantial, adverse impact upon performance ofthis Agreement without prejudice toany0therhght orremedy CITY may have under this Agreement. Notwithstanding the aforementioned, in the event of a default by CONTRACTOR, the CITY shall have the right to exercise any other remedy the CITY may have by operation of law, without limitation, and without any further demand or notice. In the event Cfsuch termination, CITY shall beliable only for the payment ofall unpaid charges, determined inaccordance with the provisions of this Agreement, for work properly performed prior to the effective date of termination. 9. FORCE MAJEURE - Any delay orfailure ofeither party in the performancenfits required obligations hereunder shall be excused if and to the extent caused by acts of God; fine; fkonH. windstorm; explosion; riot, war, sabotage; strikes (except involving CONTRACTOR's labor force); extraordinary breakdown of or damage to CITY's affiliates' generating plants, their equipment or facilities; court injunction or order, federal and/or state law or regulation; order by any regulatory agency, or cause or causes beyond the reasonable control of the party affected; provided that prompt notice of such delay is given by such party to the other and each of the parties hereunto shall be diligent in attempting to remove such cause or causes. If any circumstance of Force K4 'eune remains in effect for sixty days, either party may terminate this Agreement. 10. SEVERABILITY - In the event any portion or part thereof of this Agreement is deemed invalid, against public policy, void or otherwise unenforceable by a court of law, the parties, at the sole discretion and option of the CITY, shall negotiate on equitable adjustment in the affected provision of this Agreement. The validity and enforceability of the remaining parts of this Agreement shall otherwise befully enforceable 11. -CITYshaUmake progress payments on account of the contract price to CONTRACTOR on the basis of application for payments submitted to the CITY or[|Tfs Project Manager, by CONTRACTOR as the work progresses and in accordance with the Contract Documents. Progress payments may be withheld if. a. Work isfound defective and not remedied; b. CONTRACTOR does not make prompt and proper payments tosubcontractors; c CONTRACTOR does not make prompt and proper payments for labor, materials, or equipment furnished him; d Another Contractor isdamaged byanact for which CONTRACTOR isresponsible; AGREEMENT City of Cape Canaveral 7404N.Atlantic Avenue Property Demolition e. Claims or liens are filed on the job; or f |nthe opinion ofthe City qfCape Canaveral, work i5not progressing 12. ENT CITY shall withhold upbo596ofthe Contract Price throughout the project in accordance with House Bill HB 101. CITY shall make final payment to CONTRACTOR within thirty (30) days after the work is fully and properly completed, if the contract has been fully and timely performed, but subject tnthe condition that final payment shall not be due until CONTRACTOR has delivered to CITY a complete release of liens arising out of the contract or receipt of releases of lien fully covering all labor, materials and equipment for which a lien could be filed, or in the alternative a bond satisfactory to CITY indemnifying him against such claims. Bvmaking payments, CITY does not waive claims including but not limited tothose relating to: a. Faulty work appearing after substantial completion has been granted; b. Work that does not comply with the Contract Documents; [ Outstanding claims Ofliens; or d. Failure ofCONTRACTOR to comply with any special guarantees required by the Contract Documents. 13. DESIGNATION OF PROJECT ARCHITECT OR ARCHITECT: DUTIES.AND AUTHORITY -Theduties and authority of the CITY are asfollows: o. General Administration of Contract. The primary function ofthe CITY isto provide the general administration of the contract. In performance of these duties, Dave Dickey or his authorized representative isthe OTYsProject Managerduhngtheentinepehodofvvork. The CITY may change the Project Manogerduringthetgrrnofthiscnntract. b. The CITY shall bekept familiar with the progress and quality of the work by CONTRACTOR and may make periodic visits to the work site, The CITY will not be responsible for the means of the work, or for the sequences, methods and procedures used therein, orfor the CONTRACTOR'S failure to perform the work in accordance with the Contract Documents. c Access to Worksite for inspections. The CITY shall begiven free access tothe wmrkshe etall times during work preparation and progress. The Project Managerisnotob|igotedto make exhaustive or continuous onsite inspections to perform his duties of checking and reporting on work progress, and any such inspections shall not waive CITY's claim regarding defective work bvCONTRACTOR. AGREEMENT City ofCape Canaveral 74O4N.Atlantic Avenue Property Demolition dL The CITY will be the initial interpreter of the contract document requirements, and make decisions on claims and disputes between CONTRACTOR and CITY. e. Rpjgction and Sto aqq of Work. The CITY shall have authority toreject work which in its opinion does not conform tothe Contract Documents, and in this connection may stop the work or a portion thereof, when necessary. f Pa ent Certificates. The CITY will determine the amounts owing toCONTRACTOR as the work progresses, based on CONTRACTOR's applications and CITY's inspections and observations, and will issue certificates for progress payments and final payments in accordance with the terms qfthe Contract Documents. 14` PROGRESS — [D`/'s Project Manager may hold periodic progress meetings on a monthly basis, or more frequently if required by the CITY, during the term of work entered into under this Agreement. C{}NTRA[T(]R'sProject K4anmgerandal|otherappvophate9esonnm| shall attend such meetings os designated hwthe [|lY^sProject ManaQec 15. RESPONSIBILITIES QF2CQNTRACTOR-[ONTRA{]OR'sduties and rights inconnection with the project herein are as follows: a. CONTRACTOR shall be solely responsible for all work under this contract, including the techniques, sequences procedures and means, for the coordination of all work. CONTRACTOR shall supervise and direct the work, and give it all attention necessary for such proper supervision and direction. b. Discioline and Empipyment. CONTRACTOR shall maintain atall times strict discipline among his employees, and he agrees not to employ for work onthe project any person unfit or without sufficient skill to perform thejob for which he was employed. c. Furnishing Is, etc. CONTRACTOR shall provide and pay for all labor, materials and equipment, including tools, demolition equipment and machinery, utilities, including water, transportation, and all other facilities and vvod« necessary for the proper completion ofwork onthe project in accordance with the Contract Documents. d. Pavment of Taxes: Procurement and Permits. CONTRACTOR shall secure all licenses and permits necessary for proper completion of the work, payingthe fees thereof. CONTRACTOR warrants that it (and subcontractors or tradesmen, if authorized in the Contract Documents) hold or will secure all trade or professional licenses required h»law for CONTRACTOR toundertake the contract work. e` CONTRACTOR will provide written guarantee for work and materials for one (1) AGREEMENT City m[Cape Canaveral 74U4N.Atlantic Avenue Property Demolition 16 ASSIGNMENT- CONTRACTOR shall not assign orsubcontract this Agreement, 0rany rights or any monies due or to become due hereunder without the prior, written consent of the CITY. a' If upon receiving written approval from CRY, any part of this Agreement is subcontracted by CONTRACTOR, CONTRACTOR shall be fully responsible to CITY for all acts and/or omissions performed by the subcontractor as if no subcontract had been made. b. If CITY determines that any subcontractor is not performing in accordance with this Agreement, CITY shall so notify CONTRACTOR who shall take immediate steps to remedy the situation. c IfCONTRACTOR, prior to the commencement of any work subcontracts any part of this Agreement by the subcontractor, CONTRACTOR shall require the subcontractor to provide CITY and its affiliates with insurance coverage as set forth by the CITY, 17. THIRD -NothinginthisAoreement shall beconstrued to give any rights or benefits tnanyone other than CITY and CONTRACTOR. l& PROHIBITION AGAINST FEES - CONTRACTOR warrants that it has not employed orretained any company orperson, other than abona fide employee working solely for the CONTRACTOR, to solicit or secure this Agreement, and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the CONTRACTOR, any fee, commission, percentage, gift or other consideration contingent upon or resulting from the award or making of this Agreement. 19. NO JOINT VENTURE - Nothing herein shall bedeemed tncreate ajoint venture or principal - agent relationship between the parties and neither party is authorized to, nor shall either party act toward third persons or the public in any manner which would indicate any such relationship with the other party. 20INDEMNIFICATION, — For other and additional good and valuable consideration, the receipt and sufficiency of which ishereby acknowledged, the CONTRACTOR shall indemnify, hold harmless and defend the CITY, its officers, agents, officials, representatives,employees, and/or attorneys against any and all liability, loss, cost damages, expenses, claim or e{±ions, of whatever type, including but not limited to attorney's fees and suit costs, for trial and appeal, which the CITY may hereafter sustain, incur or be required to pay, arising out of wholly or in part, or due to any act or omission of CONTRACTOR, its agent(s)' vendors, contractors, subcontractor(s), representatives, servants or employees in the execution, performance or non- performance or failure to adequately perform [ONTRA[T{]R's obligations pursuant to this Agreement. The indemnification provided above shall obligate the indemnifying party to defend atits own expense ortoprovide for such defense, etthe sole option ofthe CITY, asthe case may be, of any and all claims ofliability and all suits and actions Ofevery name and description that may AGREEMENT City of Cape Canaveral 7404N.Atlantic Avenue Property Demolition be brought against the CITY, its officers, agents officials, representatives, employees,and/or attorneys which may result from the services under this Agreement whether the services be performed by the indemnifying party oranyone directly or indirectly employed or hired by them. In all events the CITY shall be permitted to choose legal counsel of its sole choice, the fees for which shall be subject to and included with this indemnification provided herein, as long as said fees are reasonable. This paragraph shall survive termination of this Agreement. 21. SAFETY - CONTRACTOR shall be solely and absolutely responsibleand assume all liability for the safety and supervision of its principals, employees contractors, and agents while performing work provided hereunder. 22. CORPORATE REPRESENTATIONS BY CONTRACTOR - andwarrants to the CITY the following: a CONTRACTOR is duly registered and licensed to do business inthe State ofFlorida and is in good standing under the laws cfFlorida, and isduly qualified and authorized tocarry on the functions and operations set forth in this Agreement. b. The undersigned signatory for CONTRACTOR has the power, authority, and the legal right to enter into and perform the obligations set forth in this Agreement and all applicable exhibits thereto, and the execution, delivery, and performance hereof by CONTRACTOR has been duly authorized by the board of directors and/or president of CONTRACTOR. In support of said representation, CONTRACTOR agrees to provide acopy tnthe CITY of corporate certificate of good standing provided by the State of Florida prior tothe execution ofthis Agreement. c CONTRACTOR is duly licensed under all local, state and federal laws to provide the work stated in paragraph 1.0 herein. In support of said representation, CONTRACTOR agrees to provide a copy of all said licenses to the CITY prior to the execution of this Agreement. 23. BOND - Materials, performance and payment bond(s) will not be required for this work. 24, INSURANCE -During the term of this Agreement, CONTRACTOR shall be responsible for providing the types of insurance and limits of liability as set forth below. a. The CONTRACTOR shall maintain comprehensive general liability insurance in the minimum amount Vf$1, asthe combined single limit for each occurrence toprotect the CONTRACTOR from claims of property damages which may arise from any vvod« performed under this Agreement whether such work is performed by the CONTRACTOR orbyanyone directly employed byorcontracting with the CONTRACTOR. b. The CONTRACTOR shall maintain comprehensive automobile liability insurance inthe minimum amount of $1,000000 combined single limit bodily injury and rnininlurn AGREEMENT City of Cape Canaveral 7404 N. Atlantic Avenue Property Demolition the CONTRACTOR from claims for damages for bodily injury, including wrongful death, as well as from claims from property damage, which may arise from the ownership, use, or maintenance of owned and non -owned automobiles, including rented automobiles whether such operations be by the CONTRACTOR or by anyone directly or indirectly employed by the CONTRACTOR. c. The CONTRACTOR shall maintain, during the life of this Agreement, adequate Workers' Compensation Insurance in at least such amounts as are required by law and Employer's Liability Insurance in the minimum amount of $2,000,000 for all of its employees performing work for the CITY pursuant to this Agreement. Special Requirements. Current, valid insurance policies meeting the requirements herein identified shall be maintained during the term of this Agreement. A copy of a current Certificate of Insurance shall be provided to the CITY by CONTRACTOR upon the Effective Date of this Contract which satisfies the insurance requirements of this paragraph 24. Renewal certificates shall be sent to the CITY 30 days prior to any expiration date. There shall also be a 30-day advance written notification to the CITY in the event of cancellation or modification of any stipulated insurance coverage. The CITY shall be an additional named insured on all stipulated insurance policies as its interest may appear, from time to time, excluding workers' compensation and professional liability policies. Independent Associates and Consultants. All independent contractors or agents employed by CONTRACTOR to perform any work hereunder shall fully comply with the insurance provisions contained in this paragraph section 24. 25. MEDIATION/VENUE - The parties agree that should any dispute arise between them regarding the terms or performance of this Agreement, both parties will participate in mediation. The parties agree to equally share the cost of the mediator. Should the parties fail to resolve their differences through mediation, then any cause of action filed hereunder shall be filed in the Circuit or County Court for Brevard County, Florida. 26. GOVERNING L.A1N & VENUE - This Agreement is made and shall be interpreted, construed, governed, and enforced in accordance with the laws of the State of Florida. Venue for any state action or litigation shall be Brevard County, Florida. Venue for any federal action or litigation shall be Orlando, Florida. 27. ATTORNEY'S FEES - Should either party bring an action to enforce any of the terms of this Agreement, the prevailing party shall be entitled, to the extent permitted by law, to recover from the non -prevailing party the costs and expenses of such action including, but not limited to, reasonable attorney's fees, whether at settlement, trial or on appeal. 28. NOTICES - Any notice or approval under this Contract shall be sent, postage prepaid, to the applicable party at the address shown in Section 36 of this Agreement. AGREEMENT City ofCape Canaveral 7404N.Atlantic Avenue Property Demolition 29 IS A PRIVATE UNDERTAKING - With regard toany and all work performed hereunder, it is specifically understood and agreed to by and between the parties hereto that the contractual relationship between the CITY and CONTRACTOR is such that the CONTRACTOR is an independent contractor and not an agent of the CITY. The CONTRACTOR, its contractors, partners, agents, and their employees are independent contractors and not employees of the CITY. Nothing in this Agreement shall be interpreted to establish any relationship other than that of an independent contractor, between the CITY, onone hand, and the CONTRACTOR, its contractors, partners, employees, or agents, during or after the performance of the work under this Agreement 30DOCUMENTS - Public Records: Pursuant to Section 119.0701, Florida Statutes and other applicable public records lows, CONTRACTOR agrees that any records, documents, transactions, writings, papers, letters, computerized information and programs, maps, books, audio orvideo tapes, films, photographs, data processing software, writings or other material(s), regardless of the physical fo/no' characteristics or means of transmission, of CONTRACTOR related, directly or indirectly, to the services provided to the CITY under this Agreement and made or received pursuant to law or ordinance or in connection with the transaction of official business bythe CITY, may be deemed to be a public record, whether in the possession or control of CITY or the [{JNTRA[T[J& Said records' documents, transactions, writings, papers. letters, computerized information and programs, maps, books, audio or Video tapes, filmns, photographs, data processing software, writings or other material(s), regardless of the physical form, characteristics or means of transmission of CONTRACTOR are subject to the provisions of Chapter 119, Florida Statutes' and may not be destroyed without the specific written approval ofthe [|TY'sdesignated custodian ofpublic records. IF THE CONTRACTORHAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THUS AGREEMENT, CONTACT THE CUTY'S CUSTODIAN OF PUBLIC RECORDS/CITY CLERK AT (321) 868-1220, 100 POL0C AVENUE, CAPE CANAVERAK~ FLORIDA 32920. CONTRACTOR isrequired toand agrees to comply with public records laws, CONTRACTOR shall keep and maintain all public records required by CITY to perform the services as agreed to herein. CONTRACTOR shall provide the CITY, upon request from the CITY CLERK, copies of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided by law. CONTRACTOR shall ensure that public records that are exempt orconfidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the Agreement term. Upon completion ofthe Agreement, CONTRACTOR shall transfer to CITY, at no cost' all public records in possession of the CONTRACTOR, provided the transfer is requested in writing bythe City Clerk. Upon such transfer, CONTRACTOR shall destroy any duplicate public records that are gxgnnot or confidential and exempt from public records disclosure requirements. However, if the City Clerk does not request that the public records be transferred, the CONTRACTOR shall continue to keep and maintain the public records upon AGREEMENT City of Cape Canaveral 7404N.Atlantic Avenue Property Demolition completion nfthe Agreement and shall meet all applicable requirements for retaining public records. All records stored electronically must beprovided 10CITY, upon request from the City Clerk, in a format that is compatible with the information technology systems of CITY. Should the CITY not possess public records relating to this Agreement which are requested to be inspected or copied by the CITY orany other person, the CITY shall immediately notify CONTRACTOR of the request and the CONTRACTOR shall then provide such records to the CITY or a||ovv the records to be inspected or copied within o reasonable time. If the CONTRACTOR does not comply with a public records request the CITY may enforce this Section to the extent permitted by law. CONTRACTOR acknowledges that if the CONTRACTOR does not provide the public records to the CITY within a reasonable time, the CONTRACTOR may be subject to penalties under Section 119.10' Florida Statutes. The CONTRACTOR acknowledges that ifocivil action isfiled against the CONTRACTOR tocompel production of public records relating to this Agreement, the court may assess and award against CONTRACTOR the reasonable costs of enforcement, including reasonable attorney fees. All public records inconnection with this Agreement shall, otany and all reasonable times during the normal business hours of the CONTRACTOR, be open and freely exhibited to the CITY for the purpose of examination, audit or otherwise. Failure by CONTRACTOR to grant such public access and comply with public records laws and/or requests shall be grounds for immediate unilateral cancellation of this Agreement by the CITY upon delivery of written notice of cancellation. If the CONTRACTOR fails to comply with this Section, and the CITY must enforce this Section, or the CITY suffers a third party award of attorney's fees and/or damages for violating Chapter 119, Florida Statutes, due to[ONTR/\CT{}R'sfailure tncomply with this Section, the CITY shall collect from CONTRACTOR prevailing party attorney's fees and costs, and any damages incurred by the CITY, for enforcing this Section against CONTRACTOR. And, if applicable, the CITY shall also be entitled to reimbursement of all attorneys' fees and damages which the CITY had to pay a third party because of the CONTRACTOR's failure to comply with this Section. The terms and conditions set forth in this Section shall survive the termination nfthis Agreement. 31. SOVEREIGN IMMUNITY - Notwithstanding any other provision set forth in this Agreement nothing contained in this Agreement shall be construed as a waiver of the C|TYs right to sovereign immunity under Section 768.28, or other limitations imposed on the CITY's potential liability under state mrfederal law, Assuch, the CITY shall not beliable, under this Agreement for punitive damages or interest for the period beforejudgment. Further, the CITY shall not be liable for any claim or judgment, mrportion thereof, to any one person for more than two hundred thousand dollars ($200,000.00), or any claim orjudgment, or portion thereof, which, when totaled with all other claims or judgments paid by the State o/ its agencies and subdivisions arising out of the same incident or occurrence, exceeds the sum of three hundred thousand dollars ($300,000.0[). 32. H-Paragraph headings are for the convenience of the par -ties only and are not to be AGREEMENT City ofCape Canaveral 7404N. Atlantic Avenue Property Demolition 33. N-Thedrafting execution, and delivery of this Agreement by the Parties has been induced by no representations, statements, warranties, or agreements other than those expressed herein. This Agreement embodies the entire understanding cf the parties, and there are nofurther orother agreements or understandings, written or oral, in effect between the parties relating to the subject matter hereof unless expressly referred to herein. Modifications ofthis Agreement shall only be made in writing signed by both parties. 34. WAIVER AND ELECTION OF REMEDIES - Waiver 6«either party ofany terms or provisionof this Agreement shall not be considered a waiver of that term, condition, or provision in the future. Nowaiver, consent, ormodification ofany mfthe provisions ofthis Agreement shall be binding unless inwriting and signed byaduly authorized representative ofeach party hereto. This Agreement may be executed in any number nfcounterparts, each of which when so executed and delivered shall be considered an original agreement; but such counterparts shall together constitute but one and the same instrument. 35. DRAFTING - CITY and CONTRACTOR each represent that they have both shared equally in drafting this Agreement and no party shall be favored or disfavored regarding the interpretation of this Agreement in the event of a dispute between the parties. 36. NOTICE -Any notice, request, instruction, or other document to begiven aspart of this Agreement shall be in writing and shall be deemed given under the following circumstances: when delivered in person; or three (3) business days after being deposited in the United States Mai[ postage prepoid, certified or registered; or the next business day after being deposited with a recognized overnight mail or courier delivery service; or when transmitted by facsimile or te|ecopy transmission, with receipt acknowledged upon transmission; and addressed as follows (or to such other person or at such other address, of which any party hereto shall have given written notice as provided herein): For City: City ofCape Canaveral Todd Marley, City Manager 1OOPolk Avenue Cape Canaveral, FL 32920 Phone: 321-888-1220 Fax: 331-868-1248 For � 5 / Either party may change the notice address by providing the other party written notice of the change. IN WITNESS WHEREOF, the parties hereto have executed this Agreement asofthe day and year first above written, AGREEMENT City of Cape Canaveral 7404 N. Atlantic Avenue Property Demolition Print Name: rtifie-N Attest: c2 By: f' la Goforth, ety Clerk CONTRACTOR: Title: CITY: City of Cape Canaveral, Florida, a Florida municipal corporation. Date AGREEMENT