Loading...
HomeMy WebLinkAboutcocc_chinchor_electric_scada_agreement_20210506City of Cape Canaveral SCADA Improvements CONSTRUCTION AGREEMENT This Agreement made this 6 th day of May , 2021 between the CITY OF CAPE CANAVERAL, a Florida municipal corporation (herein referred to as CITY) and Chinchor Electric, Inc., a State Certified General Construction Firm authorized and duly licensed to do business in the State of Florida (herein referred to as CONTRACTOR), as follows: 1. DESCRIPTION OF WORK - CONTRACTOR shall perform the work, in accordance with the Contract Documents, for SCADA improvements as set forth in the Scope of Services, attached hereto as Exhibit "A", and fully incorporated by this reference ("Work"). 2. CONTRACT DOCUMENTS - The Contract Documents consist of this Agreement; Exhibits and Addenda to the Agreement; Engineering Plans and Drawings prepared by Stantec, Inc., dated January 2021, Bid #2021-01; Documents issued by the CITY; CONTRACTOR'S Bid Submittal; General Conditions by the CITY; Supplemental Terms and Conditions by the CITY and Florida Department of Environmental Protection (FDEP); and all Change Orders approved by the CITY after execution of this Agreement. These Contract Documents are hereby incorporated into this Contract by this reference. 3. ORDER OF PRECEDENCE - In case of any inconsistency in any of the documents bearing on the Agreement between the CITY and the CONTRACTOR, the inconsistency shall be resolved by giving precedence in the following order: a. Agreement Exhibits and Addenda; CONTRACTOR'S Bid Submittal; b. Change Orders; c. Supplemental Terms and Conditions (CITY and FDEP); d. General Terms and Conditions; or e. Engineering Plans and Drawings. Any inconsistency in the work description shall be clarified by the CITY and performed by the CONTRACTOR. 4. AGREEMENT INTERPRETATION - At its discretion, during the course of the work, should any errors, ambiguities or discrepancies be found in the Agreement or specifications, the CITY at its sole discretion will interpret the intent of the Agreement and work descriptions and the CONTRACTOR hereby agrees to abide by the CITY's interpretation and agrees to carry out the work in accordance with the decision of the CITY. When the material, article or equipment is designated by a brand name and more than one brand name is listed, it will be understood that the work is based on one brand name only. The CONTRACTOR will be responsible for all coordination necessary to accommodate the material, article or equipment being provided CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements without additional cost to the CITY. A substitute material, article or equipment is allowed if it is reasonably equivalent to the brand name specified. The CITY has full discretion to decide whether a substitute is reasonably equivalent. CONTRACTOR must notify the CITY prior to use of the substitute for a specified brand name and allow the CITY to make a determination before CONTRACTOR uses the substitute. 5. CONTRACT TIME - The CONTRACTOR shall begin work within thirty (30) days after the issuance of a written Notice to Proceed and shall complete the Work (substantial completion) within 330 calendar days. The CONTRACTOR shall complete the Work (final completion) within 360 calendar days from the date of the Notice to Proceed. Extensions, if any, are authorized by CITY, and may only be granted in writing. 6. LIQUIDATED DAMAGES - CITY and CONTRACTOR recognize that time is of the essence of this Agreement and that CITY will suffer financial loss if the Work is not substantially complete within the time specified in Paragraph 5 above, plus any extensions thereof allowed in accordance with the General Conditions. They also recognize the delays, expense and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by CITY if the Work is not substantially completed on time. Accordingly, instead of requiring any such proof, CITY and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay CITY one hundred dollars ($100.00) per day for each day that expires after the time specified in Paragraph 5 for final completion until the work is finally complete, and that CITY has paid to CONTRACTOR the consideration of ten ($10.00) dollars as consideration for this provision. 7. CONTRACT PRICE, UNIT PRICE CONTRACT - The CITY will pay the CONTRACTOR in current funds for the performance of the work, subject to additions and deductions by Change Order, the Total Contract Price of $723,211 (seven hundred twenty-three thousand, two hundred eleven dollars and no cents). Payments will be made to the CONTRACTOR for actual quantities installed on the basis of the Schedule of Unit Prices included as a part of the Bid, which shall be as fully a part of the Contract as if attached or repeated herein. Owner direct purchase (ODP) will be in effect for all items over $10,000 in cost. 8. TERMINATION; DEFAULT BY CONTRACTOR AND CITY'S REMEDIES - The CITY reserves the right to revoke and terminate this Agreement and rescind all rights and privileges associated with this Agreement, without penalty, for convenience. Further, the CITY reserves the right to revoke and terminate this Agreement in the following circumstances, each of which shall represent a default and breach of this Agreement: a. CONTRACTOR defaults in the performance of any material covenant or condition of this Agreement and does not cure such other default within seven (7) calendar days after written notice from the CITY specifying the default complained of unless, however, the nature of the default is such that it cannot, in the exercise of reasonable diligence, be remedied within seven (7) calendar days, in which case the CONTRACTOR shall have such CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements time as is reasonably necessary to remedy the default, provided the CONTRACTOR promptly takes and diligently pursues such actions as are necessary therefore; or b. CONTRACTOR is adjudicated bankrupt or makes any assignment for the benefit of creditors or CONTRACTOR becomes insolvent, or is unable or unwilling to pay its debts; or c. CONTRACTOR has acted negligently, as defined by general and applicable law, in performing the Work hereunder; or d. CONTRACTOR has committed any act of fraud upon the CITY; or e. CONTRACTOR has made a material misrepresentation of fact to the CITY while performing its obligations under this Agreement; or f. CONTRACTOR is experiencing a labor dispute, which threatens to have a substantial, adverse impact upon performance of this Agreement without prejudice to any other right, or remedy CITY may have under this Agreement. Notwithstanding the aforementioned, in the event of a default by CONTRACTOR, the CITY shall have the right to exercise any other remedy the CITY may have by operation of law, without limitation, and without any further demand or notice. In the event of such termination, CITY shall be liable only for the payment of all unpaid charges, determined in accordance with the provisions of this Agreement, for Work properly performed prior to the effective date of termination. 9. FORCE MAJEURE - Any delay or failure of either party in the performance of its required obligations hereunder shall be excused if and to the extent caused by acts of God; fire; flood; windstorm; explosion; riot; war; sabotage; strikes (except involving CONTRACTOR's labor force); extraordinary breakdown of or damage to CITY's affiliates' generating plants, their equipment or facilities; court injunction or order; federal and/or state law or regulation; order by any regulatory agency; or cause or causes beyond the reasonable control of the party affected; provided that prompt notice of such delay is given by such party to the other and each of the parties hereunto shall be diligent in attempting to remove such cause or causes. If any circumstance of Force Majeure remains in effect for sixty days, either party may terminate this Agreement. 10. SEVERABILITY - In the event any portion or part thereof of this Agreement is deemed invalid, against public policy, void or otherwise unenforceable by a court of law, the parties, at the sole discretion and option of the CITY, shall negotiate an equitable adjustment in the affected provision of this Agreement. The validity and enforceability of the remaining parts of this Agreement shall otherwise be fully enforceable 11. PROGRESS PAYMENTS - CITY shall make progress payments on account of the contract price to CONTRACTOR, on the basis of application for payments submitted to the CITY or CITY's CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements Project Manager, by CONTRACTOR as the work progresses and in accordance with the Contract Documents. Progress payments may be withheld if: a. Work is found defective and not remedied; b. CONTRACTOR does not make prompt and proper payments to subcontractors; c. CONTRACTOR does not make prompt and proper payments for labor, materials, or equipment furnished him; d. Another Contractor is damaged by an act for which CONTRACTOR is responsible; e. Claims or liens are filed on the job; or f. In the opinion of the City of Cape Canaveral, CONTRACTOR'S work is not progressing satisfactorily. 12. FINAL PAYMENT - CITY shall withhold up to 5% of the Contract Price throughout the project in accordance with the Local Government Prompt Payment Act ("Act"). After 50% completion of the project, CITY shall reduce to 0% the amount of the retainage withheld from each subsequent progress payment made to the CONTRACTOR unless the project is subject to Federal funding, in whole or in part, and the project is subject to laws and regulations contrary to the Act. The term "50% completion of the project" shall mean the point at which the CITY has expended 50% of the total cost of the construction services purchased under this Agreement together with all costs associated with existing change orders and other additions or modifications to the construction services provided for in this Agreement. After 50% completion, the CONTRACTOR may present to the CITY a payment request for up to one-half of the retainage held by the CITY. CITY shall promptly make payment to the CONTRACTOR unless the CITY has grounds, under the Act, for withholding the payment of the retainage. The remaining retainage amount withheld shall be released with the Final Payment after the issuance of the Final Completion Certificate. CITY shall make final payment to CONTRACTOR within thirty (30) days after the work is fully and properly completed, if the contract has been fully and timely performed, but subject to the condition that final payment shall not be due until CONTRACTOR has delivered to CITY a complete release of liens arising out of the contract, or receipt of releases of lien fully covering all labor, materials and equipment for which a lien could be filed, or in the alternative a bond satisfactory to CITY indemnifying him against such , claims. By making payments, CITY does not waive claims including but not limited to those relating to: a. Faulty work appearing after substantial completion has been granted; CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements b. Work that does not comply with the Contract Documents; c. Outstanding claims of liens; or d. Failure of CONTRACTOR to comply with any special guarantees required by the Contract Documents. 13. DESIGNATION OF PROJECT MANAGER OR ARCHITECT OR LANDSCAPE ARCHHTECT: DUTIES AND AUTHORITY - The duties and authority of the CITY are as follows: a. General Administration of Contract. The primary function of the CITY is to provide the general administration of the contract. In performance of these duties, Jeff Ratliff or his authorized representative is the CITY's Project Manager during the entire period of construction. The CITY may change the Project Manager during the term of this contract. b. Inspections, Opinions, and Progress Reports. The CITY shall be kept familiar with the progress and quality of the work by CONTRACTOR and may make periodic visits to the work site. The CITY will not be responsible for the means of construction, or for the sequences, methods and procedures used therein, or for the CONTRACTOR'S failure to perform the work in accordance with the Contract Documents. c. Access to Worksite for Inspections. The CITY shall be given free access to the worksite at all times during work preparation and progress. The Project Manager is not obligated to make exhaustive or continuous onsite inspections to perform his duties of checking and reporting on work progress, and any such inspections shall not waive CITY's claim regarding defective work by CONTRACTOR. d. Interpretation of Contract Documents: Decisions on Disputes. The CITY will be the initial interpreter of the contract document requirements, and make decisions on claims and disputes between CONTRACTOR and CITY. e. Rejection and Stoppage of Work. The CITY shall have authority to reject work which in its opinion does not conform to the Contract Documents, and in this connection may stop the work or a portion thereof, when necessary. f. Payment Certificates. The CITY will determine the amounts owing to CONTRACTOR as the work progresses, based on CONTRACTOR's applications and CITY's inspections and observations, and will issue certificates for progress payments and final payments in accordance with the terms of the Contract Documents. 14. PROGRESS MEETING — CITY's Project Manager may hold periodic progress meetings on a monthly basis, or more frequently if required by the CITY, during the term of work entered into under this Agreement. CONTRACTOR'S Project Manager and all other appropriate personnel shall attend such meetings as designated by the CITY's Project Manager. CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements 15. RESPONSIBILITIES OF CONTRACTOR - CONTRACTOR's duties and rights in connection with the project herein are as follows: a. Responsibility for Supervision and Construction. CONTRACTOR shall be solely responsible for all construction under this contract, including the techniques, sequences, procedures and means, for the coordination of all work. CONTRACTOR shall supervise and direct the work, and give it all attention necessary for such proper supervision and direction. b. Discipline and Employment. CONTRACTOR shall maintain at all times strict discipline among his employees, and he agrees not to employ for work on the project any person unfit or without sufficient skill to perform the job for which he was employed. c. Furnishing of Labor. Materials. etc. CONTRACTOR shall provide and pay for all labor, materials and equipment, including tools, construction equipment and machinery, utilities, including water, transportation, and all other facilities and work necessary for the proper completion of work on the project in accordance with the Contract Documents. d. Payment of Taxes: Procurement of Licenses and Permits. CONTRACTOR shall secure all licenses and permits necessary for proper completion of the work, paying the fees thereof. CONTRACTOR warrants that it (and subcontractors or tradesmen, if authorized in the Contract Documents) hold or will secure all trade or professional licenses required by law for CONTRACTOR to undertake the contract work. e. CONTRACTOR will provide written guarantee for work and materials for one (1) calendar year after acceptance by CITY. 16. ASSIGNMENT - CONTRACTOR shall not assign or subcontract this Agreement, or any rights or any monies due or to become due hereunder without the prior, written consent of the CITY. a. If upon receiving written approval from CITY, any part of this Agreement is subcontracted by CONTRACTOR, CONTRACTOR shall be fully responsible to CITY for all acts and/or omissions performed by the subcontractor as if no subcontract had been made. b. If CITY determines that any subcontractor is not performing in accordance with this Agreement, CITY shall so notify CONTRACTOR who shall take immediate steps to remedy the situation. c. If CONTRACTOR, prior to the commencement of any Work subcontracts any part of this Agreement by the subcontractor, CONTRACTOR shall require the subcontractor to provide CITY and its affiliates with insurance coverage as set forth by the CITY. 17. THIRD PARTY RIGHTS - Nothing in this Agreement shall be construed to give any rights or benefits to anyone other than CITY and CONTRACTOR. CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements 18. PROHIBITION AGAINST CONTINGENT FEES - CONTRACTOR warrants that it has not employed or retained any company or person, other than a bona fide employee working solely for the CONTRACTOR, to solicit or secure this Agreement, and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the CONTRACTOR, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. 19. NO JOINT VENTURE - Nothing herein shall be deemed to create a joint venture or principal - agent relationship between the parties and neither party is authorized to, nor shall either party act toward third persons or the public in any manner which would indicate any such relationship with the other party. 20. INDEMNIFICATION m For other and additional good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the CONTRACTOR shall indemnify, hold harmless and defend the CITY, its officers, agents, officials, representatives, employees, and/or attorneys against any and all liability, loss, cost, damages, expenses, claim or actions, of whatever type, including but not limited to attorney's fees and suit costs, for trial and appeal, which the CITY may hereafter sustain, incur or be required to pay, arising out of, wholly or in part, or due to any act or omission of CONTRACTOR, its agent(s), vendors, contractors, subcontractor(s), representatives, servants or employees in the execution, performance or non- performance or failure to adequately perform CONTRACTOR's obligations pursuant to this Agreement. The indemnification provided above shall obligate the indemnifying party to defend at its own expense or to provide for such defense, at the sole option of the CITY, as the case may be, of any and all claims of liability and all suits and actions of every name and description that may be brought against the CITY, its officers, agents, officials, representatives, employees, and/or attorneys which may result from the services under this Agreement whether the services be performed by the indemnifying party or anyone directly or indirectly employed or hired by them. In all events the CITY shall be permitted to choose legal counsel of its sole choice, the fees for which shall be subject to and included with this indemnification provided herein, as long as said fees are reasonable. This paragraph shall survive termination of this Agreement. 21. SAFETY - CONTRACTOR shall be solely and absolutely responsible and assume all liability for the safety and supervision of its principals, employees, contractors, and agents while performing work provided hereunder. 22. CORPORATE REPRESENTATIONS BY CONTRACTOR - CONTRACTOR hereby represents and warrants to the CITY the following: a. CONTRACTOR is duly registered and licensed to do business in the State of Florida and is in good standing under the laws of Florida, and is duly qualified and authorized to carry on the functions and operations set forth in this Agreement. CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements b. The undersigned signatory for CONTRACTOR has the power, authority, and the legal right to enter into and perform the obligations set forth in this Agreement and all applicable exhibits thereto, and the execution, delivery, and performance hereof by CONTRACTOR has been duly authorized by the board of directors and/or president of CONTRACTOR. In support of said representation, CONTRACTOR agrees to provide a copy to the CITY of a corporate certificate of good standing provided by the State of Florida prior to the execution of this Agreement. c. CONTRACTOR is duly licensed under all local, state and federal laws to provide the work stated in paragraph 1.0 herein. In support of said representation, CONTRACTOR agrees to provide a copy of all said licenses to the CITY prior to the execution of this Agreement. 23. BOND - CONTRACTOR shall supply a materials, performance and payment bond(s) in form approved by the CITY's City Attorney and in accordance with Florida law and in an amount specified in the Contract Documents. 24. INSURANCE - During the term of this Agreement, CONTRACTOR shall be responsible for providing the types of insurance and limits of liability as set forth below. a. The CONTRACTOR shall maintain comprehensive general liability insurance in the minimum amount of $2,000,000 as the combined single limit for each occurrence to protect the CONTRACTOR from claims of property damages which may arise from any Work performed under this Agreement whether such Work is performed by the CONTRACTOR or by anyone directly employed by or contracting with the CONTRACTOR. b. The CONTRACTOR shall maintain comprehensive automobile liability insurance in the minimum amount of $1,000,000 combined single limit bodily injury and minimum $1,000,000 property damage as the combined single limit for each occurrence to protect the CONTRACTOR from claims for damages for bodily injury, including wrongful death, as well as from claims from property damage, which may arise from the ownership, use, or maintenance of owned and non -owned automobiles, including rented automobiles whether such operations be by the CONTRACTOR or by anyone directly or indirectly employed by the CONTRACTOR. c. The CONTRACTOR shall maintain, during the life of this Agreement, adequate Workers' Compensation Insurance in at least such amounts as are required by law and Employer's Liability Insurance in the minimum amount of $2,000,000 for all of its employees performing Work for the CITY pursuant to this Agreement. Special Requirements. Current, valid insurance policies meeting the requirements herein identified shall be maintained during the term of this Agreement. A copy of a current Certificate of Insurance shall be provided to the CITY by CONTRACTOR upon the Effective Date of this Contract which satisfies the insurance requirements of this paragraph 24. Renewal certificates CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements shall be sent to the CITY 30 days prior to any expiration date. There shall also be a 30-day advance written notification to the CITY in the event of cancellation or modification of any stipulated insurance coverage. The CITY shall be an additional named insured on all stipulated insurance policies as its interest may appear, from time to time, excluding workers' compensation and professional liability policies. All independent contractors or agents employed by CONTRACTOR to perform any Work hereunder shall fully comply with the insurance provisions contained in this paragraph section 24. 25. MEDIATION/VENUE - The parties agree that should any dispute arise between them regarding the terms or performance of this Agreement, both parties will participate in mediation. The parties agree to equally share the cost of the mediator. Should the parties fail to resolve their differences through mediation, then any cause of action filed hereunder shall be filed in the Circuit or County Court for Brevard County, Florida. 26. GOVERNING LAW & VENUE - This Agreement is made and shall be interpreted, construed, governed, and enforced in accordance with the laws of the State of Florida. Venue for any state action or litigation shall be Brevard County, Florida. Venue for any federal action or litigation shall be Orlando, Florida. 27. ATTORNEY'S FEES - Should either party bring an action to enforce any of the terms of this Agreement, the prevailing party shall be entitled, to the extent permitted by law, to recover from the non -prevailing party the costs and expenses of such action including, but not limited to, reasonable attorney's fees, whether at settlement, trial or on appeal. 28. NOTICES - Any notice or approval under this Contract shall be sent, postage prepaid, to the applicable party at the address shown on page 9 of this Agreement. 29. WORK IS A PRIVATE UNDERTAKING - With regard to any and all Work performed hereunder, it is specifically understood and agreed to by and between the parties hereto that the contractual relationship between the CITY and CONTRACTOR is such that the CONTRACTOR is an independent contractor and not an agent of the CITY. The CONTRACTOR, its contractors, partners, agents, and their employees are independent contractors and not employees of the CITY. Nothing in this Agreement shall be interpreted to establish any relationship other than that of an independent contractor, between the CITY, on one hand, and the CONTRACTOR, its contractors, partners, employees, or agents, during or after the performance of the Work under this Agreement. 30. DOCUMENTS - Public Records: Pursuant to Section 119.0701, Florida Statutes and other applicable public records laws, CONTRACTOR agrees that any records, documents, transactions, writings, papers, letters, computerized information and programs, maps, books, audio or video tapes, films, photographs, data processing software, writings or other material(s), regardless of the physical form, characteristics or means of transmission, of CONTRACTOR CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements related, directly or indirectly, to the services provided to the CITY under this Agreement and made or received pursuant to law or ordinance or in connection with the transaction of official business by the CITY, may be deemed to be a public record, whether in the possession or control of CITY or the CONTRACTOR. Said records, documents, transactions, writings, papers, letters, computerized information and programs, maps, books, audio or video tapes, films, photographs, data processing software, writings or other material(s), regardless of the physical form, characteristics or means of transmission of CONTRACTOR are subject to the provisions of Chapter 119, Florida Statutes, and may not be destroyed without the specific written approval of the CITY's designated custodian of public records. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS AGREEMENT, CONTACT THE CITY'S CUSTODIAN OF PUBLIC RECORDS/CITY CLERK AT (321) 868-1220, 100 POLK AVENUE, CAPE CANAVERAL, FLORIDA 32920. CONTRACTOR is required to and agrees to comply with public records laws. CONTRACTOR shall keep and maintain all public records required by CITY to perform the services as agreed to herein. CONTRACTOR shall provide the CITY, upon request from the CITY CLERK, copies of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided by law. CONTRACTOR shall ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the Agreement term. Upon completion of the Agreement, CONTRACTOR shall transfer to CITY, at no cost, all public records in possession of the CONTRACTOR, provided the transfer is requested in writing by the City Clerk. Upon such transfer, CONTRACTOR shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. However, if the City Clerk does not request that the public records be transferred, the CONTRACTOR shall continue to keep and maintain the public records upon completion of the Agreement and shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to CITY, upon request from the City Clerk, in a format that is compatible with the information technology systems of CITY. Should the CITY not possess public records relating to this Agreement which are requested to be inspected or copied by the CITY or any other person, the CITY shall immediately notify CONTRACTOR of the request and the CONTRACTOR shall then provide such records to the CITY or allow the records to be inspected or copied within a reasonable time. If the CONTRACTOR does not comply with a public records request, the CITY may enforce this Section to the extent permitted by law. CONTRACTOR acknowledges that if the CONTRACTOR does not provide the public records to the CITY within a reasonable time, the CONTRACTOR may be subject to penalties under Section 119.10, Florida Statutes. The CONTRACTOR acknowledges that if a civil action is filed against the CONTRACTOR to compel production of public records relating to this Agreement, the court may assess and award against CONTRACTOR the reasonable costs of enforcement, including reasonable attorney fees. All public records in connection with this Agreement shall, at any and all reasonable times CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements during the normal business hours of the CONTRACTOR, be open and freely exhibited to the CITY for the purpose of examination, audit or otherwise. Failure by CONTRACTOR to grant such public access and comply with public records laws and/or requests shall be grounds for immediate unilateral cancellation of this Agreement by the CITY upon delivery of a written notice of cancellation. If the CONTRACTOR fails to comply with this Section, and the CITY must enforce this Section, or the CITY suffers a third party award of attorney's fees and/or damages for violating Chapter 119, Florida Statutes, due to CONTRACTOR's failure to comply with this Section, the CITY shall collect from CONTRACTOR prevailing party attorney's fees and costs, and any damages incurred by the CITY, for enforcing this Section against CONTRACTOR. And, if applicable, the CITY shall also be entitled to reimbursement of all attorneys' fees and damages which the CITY had to pay a third party because of the CONTRACTOR's failure to comply with this Section. The terms and conditions set forth in this Section shall survive the termination of this Agreement. 31. SOVEREIGN IMMUNITY - Notwithstanding any other provision set forth in this Agreement, nothing contained in this Agreement shall be construed as a waiver of the CITY's right to sovereign immunity under Section 768.28, or other limitations imposed on the CITY's potential liability under state or federal law. As such, the CITY shall not be liable, under this Agreement for punitive damages or interest for the period before judgment. Further, the CITY shall not be liable for any claim or judgment, or portion thereof, to any one person for more than two hundred thousand dollars ($200,000.00), or any claim or judgment, or portion thereof, which, when totaled with all other claims or judgments paid by the State or its agencies and subdivisions arising out of the same incident or occurrence, exceeds the sum of three hundred thousand dollars ($300,000.00). 32. HEADINGS - Paragraph headings are for the convenience of the parties only and are not to be construed as part of this Agreement. 33. INTEGRATION; MODIFICATION - The drafting, execution, and delivery of this Agreement by the Parties has been induced by no representations, statements, warranties, or agreements other than those expressed herein. This Agreement embodies the entire understanding of the parties, and there are no further or other agreements or understandings, written or oral, in effect between the parties relating to the subject matter hereof unless expressly referred to herein. Modifications of this Agreement shall only be made in writing signed by both parties. 34. WAIVER AND ELECTION OF REMEDIES - Waiver by either party of any terms or provision of this Agreement shall not be considered a waiver of that term, condition, or provision in the future. No waiver, consent, or modification of any of the provisions of this Agreement shall be binding unless in writing and signed by a duly authorized representative of each party hereto. This Agreement may be executed in any number of counterparts, each of which when so executed and delivered shall be considered an original agreement; but such counterparts shall together constitute but one and the same instrument. CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements 35. DRAFTING - CITY and CONTRACTOR each represent that they have both shared equally in drafting this Agreement and no party shall be favored or disfavored regarding the interpretation of this Agreement in the event of a dispute between the parties. 36. NOTICE - Any notice, request, instruction, or other document to be given as part of this Agreement shall be in writing and shall be deemed given under the following circumstances: when delivered in person; or three (3) business days after being deposited in the United States Mail, postage prepaid, certified or registered; or the next business day after being deposited with a recognized overnight mail or courier delivery service; or when transmitted by facsimile or telecopy transmission, with receipt acknowledged upon transmission; and addressed as follows (or to such other person or at such other address, of which any party hereto shall have given written notice as provided herein): For City: City of Cape Canaveral Todd Morley, City Manager 100 Polk Avenue Cape Canaveral, FL 32920 Phone: 321-868-1220 Fax: 321-868-1248 For Contractor: Chinchor Electric, Inc. Timothy I. Chinchor, President 1460 S. Leavitt Ave. Orange City, FL 32763 Phone: 386-774-1020 Fax: 386-774-7223 Either party may change the notice address by providing the other party written notice of the change. IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the day and year first above written. WITNESSES: Print Name: Mali& Ptya tO Print Name: ZdtcA St rrreiexok CONTRACTOR: By: -77 Print ame: 411410-' Title: tpRe61 CONSTRUCTION AGREEMENT City of Cape Canaveral SCADA Improvements Attest: By: Mia Goforth, City erk CITY: City of Cape Canaveral, Florida, a Florida municipal corporation. By: orley, City ar a'ger Date: CONSTRUCTION AGREEMENT A` o b® CERTIFICATE OF LIABILITY INSURANCE DATE(MMlDD/YYYY) 04/22/2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the po icy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Brown & Brown of Florida, Inc. P.O. Box 2412 Daytona Beach FL 32115-2415 CONTACT Denise D'Abato NAME: (A/C, No, Eat): (386) 239-7281 FAX No): (386) 323-9121 E-MAIL ddabato@bbdaytona.com ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC # INSURERA: Amerisure Insurance Company 19488 INSURED CHINCHOR ELECTRIC, INC. 1460 SOUTH LEAVITTAVE. ORANGE CITY FL 32763 INSURER B : XL Specialty Insurance Company 37885 INSURER C: The North River Insurance Company 21105 INSURER D : LLoyd's of London INSURER E : Liberty Surplus Lines Ins. Corporation 10725 INSURER F: COVERAGES CERTIFICATE NUMBER: 20-21 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLIC ES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD - POLICY NUMBER POLICY EFF (MMIDD/YYYY) POLICY EXP (MMIDDIYYYY) LIMITS E X COMMERCIAL GENERAL LIABILITY 100043251501 08/30/2020 08/30/2021 EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE X OCCUR DAMAGE RENTED PREMISESO(Ea occurrence) $ 50,000 MED EXP (Any one person) _ $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'LAGGREGATELIMIT P POLICY OTHER: X APPLIES 7,- PER: LOC GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG $ 2,000,000 - $ A AUTOMOBILE X _ UABIUTY ANY AUTO OWNED AUTOS ONLY HIRED AUTOS ONLY _ _ SCHEDULED AUTOS NON -OWNED AUTOS ONLY CA21060480301 08/30/2020 08/30/2021 COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE (Per accident) $ PIP -Basic $ 10,000 C X UMBRELLA LIAB EXCESSLIAB X OCCUR CLAIMS -MADE 5821147125 08/30/2020 08/30/2021 EACH OCCURRENCE $ 5,000,000 AGGREGATE $ 5,000,000 PROD/C-OP $ 5,000,000 DED X RETENTION $ 0 '4 WORKERS COMPENSATION AND EMPLOYERS' LIABIUTY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y / N N N /A WC21060470301 08/30/2020 08/30/2021 X PEATUTE OTH ER E.L. EACH ACCIDENT 1 $ ,, E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L. DISEASE - POLICY LIMIT 1,000,000 $ B INLAND MARINE UM00058950MA20A 08/30/2020 08/30/2021 RENTED EQUIPMENT INSTALLATION $100,000 $250,000 DESCRIPTION OF OPERATIONS / LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) SEE NOTES FOR POLICY COVERAGE FORMS RE: SCADA SYSTEM IMPROVEMENTS CERTIFICATE HOLDER CANCELLATION CITY OF CAPE CANAVERAL 100 POLKAVENUE CAPE CANAVERAL FL 32920-0326 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ACCORD AGENCY CUSTOMER ID: LOC #: ADDITIONAL REMARKS SCHEDULE Page of AGENCY Brown & Brown of Florida, Inc. NAMED INSURED CHINCHOR ELECTRIC, INC. POLICY NUMBER See Page 1 CARRIER See Page 1 NAIC CODE See Page 1 EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance: Notes INSURER D - PROFESSIONAL/POLLUTION LIABILITY POLICY NUMBER: B0621 PCHIN000220 08/30/2020 TO 08/30/2021 PER OCCURENCE: $1,000,000 AGGREGATE: $2,000,000 CURRENT BLANKET POLICY FORMS GENERAL LIABILITY: 1.) CGL1011 0103 - DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT SUBJECT TO A POLICY AGGREGATE LIMIT 2.) CG2010 0704 -ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS- SCHEDULED PERSON OR ORGANIZATION 3.) CG2037 0704 -ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS- COMPLETED OPERATIONS 4.) CG2034 0413 -ADDITIONAL INSURED - LESSOR OF LEASED EQUIPMENT -AUTOMATIC STATUS WHEN REQUIRED IN LEASE AGREEMENT WITH YOU 5.) CG20320704 -ADDITIONAL INSURED -ENGINEERS, ARCHITECTS OR SURVEYORS NOT ENGAGED BY THE NAMED INSURED 6.) CG20110196 -ADDITIONAL INSURED -MANAGERS OR LESSORS OF PREMISES 7.) CG2012 0509 -ADDITIONAL INSURED - STATE OR GOVERNMENTAL AGENCY OR SUBDIVISION OR POLITICAL SUBDIVISION - PERMITS 8.) CG2404 0509 - WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US 9.) CGL1031 0413.- PRIMARY INSURANCE CLAUSE ENDORSEMENT (PRIMARY AND NON-CONTRIBUTORY) 10.) CGL13851210 - NOTICE OF CANCELLATION TO THIRD PARTIES AUTO LIABILITY: 1.) CA7171 0508-FLORIDAADVANTAGE COMMERCIALAUTOMOBILE BROAD FORM ENDORSEMENT (ADDITIONAL INSURED, WAIVER OF SUBROGATION) 2.) CA2001 1013-LESSOR-ADDITIONAL INSURED AND LOSS PAYEE 3.) CA7165 0911-DESIGNATED INSURED -PRIMARY NON-CONTRIBUTORY COVERAGE WHEN REQUIRED BY INSURED CONTRACT OR CERTIFICATE 4.) IL7074 0116-NOTICE OF CANCELLATION, NONRENEWAL OR MATERIAL CHANGE — THIRD PARTY WORKERS COMPENSATION: 1.) WC000313 0484-WAIVER OF OUR RIGHT TO RECOVER FROM THE OTHERS ENDORSEMENT 2.) WC990902 0607-NOTICE OF CANCELLATION AND NON -RENEWAL TO THIRD PARTIES UMBRELLA LIABILITY: 1.) FM101.0.302 0818 - EXCESS LIABILITY INSURANCE POLICY DECLARATIONS (ADDITIONAL INSURED, PRIMARY & NONCONTRIBUTORY, WAIVER OF SUBROGATION) 2.) FM2.0.1036 0612 - FLORIDA POLICYHOLDER NOTICE OF CANCELLATION FOR CERTIFICATE HOLDERS W/O SCHEDULE THE EXCESS POLICYAPPLIES IN EXCESS OF THE GENERAL LIABILITY, AUTO LIABILITYAND EMPLOYERS LIABILITY. THE INSURANCE UNDER THIS POLICY WILL FOLLOW THE SAME PROVISIONS, EXCLUSIONS, CONDITIONS AND LIMITATIONS THATARE CONTAINED IN THE APPLICABLE CONTROLLING UNDERLYING INSURANCE, UNLESS OTHERWISE DIRECTED BY THIS POLICY. EQUIPMENT: HCM050 0112-BLANKET LOSS PAYEE ACORD 101 (2008/01) © 2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD FLORIDA SURETY BONDS, INC. April 23, 2021 City of Cape Canaveral 100 Polk Avenue Cape Canaveral, FL 32920-0326 RE: AUTHORITY TO DATE BONDS AND POWERS OF ATTORNEY Principal: Chinchor Electric, Inc. Bond No: 54-235930 Project: City of Cape Canaveral SCADA Improvements Dear Sir or Madam: 620 N. Wymore Road, Suite 200 Maitland, FL 32751 407-786-7770 Fax 407-786-7766 888-786-BOND (2663) Fax 888-718-BOND (2663) www. FloridaSuretyBonds.com Please be advised that as Surety on the above referenced bond, executed on your behalf for this project, we hereby authorize you to insert the contract date onto the contract bonds and powers of attorney. Once dated, please email to Coralise@floridasuretybonds.com or fax a copy of the bonds to our office at (407) 786-7766. Sincerely, United Fire & Casualty Company cs°,0_6z Lisa A. Roseland Attorney -In -Fact & Florida Licensed Resident Agent Performance Bond Bond No. 54-235930 Executed in 3 Counterparts *Florida Surety Bonds, Inc. 620 N. Wymore Rd. Suite 200 Maitland, FL 32751 407-786-7770 CONTRACTOR: (Name, legal status and address) Chinchor Electric, Inc. 1460 S. Leavitt Avenue Orange City, FL 32763 OWNER: (Name, legal status and address) City of Cape Canaveral 386-774-1020 100 Polk Avenue Cape Canaveral, FL 32920-0326 CONSTRUCTION CONTRACT Date: SURETY: (Name, legal status and principal place of business) United Fire & Casualty Company PO Box 73909 Cedar Rapids, IA 52407-3909 321-868-1220 Amount: $723,211.00 Description: City of Cape Canaveral SCADA Improvements, Cape Canaveral, (Name and location) FL BOND Date: (Not earlier than Construction Contract Date) Amount: $723,211.00 Modifications to this Bond: ❑ None CONTRACTOR AS PRIG IPAL Company; ;.Chinchor_Electric, In Signature: - 4 :( and Title:- - . 7? i Ve"..fc-- and Title: (Any additional signatures appear on the last page of this Performance Bond.) Corporate Seal) XJSee Section 16 319-399-5700 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. This document combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. SURETY Company: (Corporate Seal) United Fire & Casualty Company Signature Name Lisa A. Roseland* Attomey-in-Fact & Florida Licensed Resident Agent (FOR INFORMATION ONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party:) By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. 1 5 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. 5 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. § 16 Modifications to this bond are as follows: THIS BOND IS GIVEN TO COMPLY WITH SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES, AND ANY ACTION INSTITUTED BY A CLAIMANT UNDER THIS BOND FOR PAYMENT MUST BE IN ACCORDANCE WITH THE NOTICE AND TIME LIMITATION PROVISIONS IN SECTION 255.05(2) OR SECTION 713.23 FLORIDA STATUTES. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. 4 Bond No. 54-235930 Payment Bond CONTRACTOR: (Name, legal status and address) Chinchor Electric, Inc. 1460 S. Leavitt Avenue Orange City, FL 32763 OWNER: (Name, legal status and address) City of Cape Canaveral 386-774-1020 100 Polk Avenue Cape Canaveral, FL 32920-0326 CONSTRUCTION CONTRACT Date: Amount: $723,211.00 321-868-1220 Executed in 3 Counterparts SURETY: (Name, legal status and principal place of business) United Fire & Casualty Company PO Box 73909 Cedar Rapids, IA 52407-3909 Description: (Name and location) City of Cape Canaveral SCADA Improvements, Cape Canaveral, FL BOND Date: (Not earlier than Construction Contract Date) Amount: $723,211.00 Modifications to this Bond: :CONTRACTOR AS P Company: Corporate Seal) =Chinchor Electric ❑ None -::Si•gnature:— Name,_ M 41 di '. and Title _ _ e it (Any additionalsignatures appear on the last page of this Payment Bond.) See Section 18 319-399-5700 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. This document combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. SURETY Company: United Fire & Casualty Company Signatur Name and Title: Lisa A. Roseland* Attorney -in -Fact & Florida Licensed Resident Agent (Corporate Seal) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party.) *Florida Surety Bonds, Inc. 620 N. Wymore Rd. Suite 200 Maitland, FL 32751 407-786-7770 By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. 5 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: THIS BOND IS GIVEN TO COMPLY WITH SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES, AND ANY ACTION INSTITUTED BY A CLAIMANT UNDER THIS BOND FOR PAYMENT MUST BE IN ACCORDANCE WITH THE NOTICE AND TIME LIMITATION PROVISIONS IN SECTION 255.05(2) OR SECTION 713.23 FLORIDA STATUTES. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users, so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. 8 ufg :N'SURANCE UNrrED FiRE & CASUALTY COMPANY, CEDAR RAPIDS, IA UNITED FIRE & INDEMNITY COMPANY, WEBSTER, TX FINANCIAL PACIFIC INSURANCE COMPANY. ROCKLIN, CA CERTIFIED COPY OF POWER OF ATI ORNI•IY (original on file at I tome Office of Company — Sec Certification) Inquiries: Surety Department 118 Second Ave SE Cedar Rapids, IA 52401 KNOW ALL PERSONS BY TIIFSE PRESENTS, That United Fire & Casualty Company, a corporation duly organized and existing under the laws of the State of Iowa; United Fire & Indemnity Company, a corporation duly organized and existing under the laws of the State of Texas; and Financial Pacific Insurance Company, a corporation duly oreani-r.cd and existing under the laws of the State of California (herein collectively called the Companies), and having their corporate headquarters in Cedar Rapids, State of Iowa, does make, constitute and appoint KIM E. NIV, JEFFREY W. REICH. SUSAN L. REICH, TERESA L. DURHAM, GLORIA A. RICHARDS, LISA A. ROSELAND, SONJA AMANDA FLOREE HARRIS, CHERYL A. FOLEY, ROBERT P. O'LINN, SARAH K. O'LINN, EMILY J. GOLECKI, JENNA R. DELGADO, CORALISE M. MEDAL, HIENEKA C. HARRINGTON, BRIANNA T. STEPHENSON, EACH INDIVIDUALLY their true and lawful Attorney(s)-in-Fact with power and authority hereby conferred to sign, seal and execute in its behalf all lawful bonds, undertakings and other obligatory instruments of similar nature pmvided that no single obligation shall exceed $100, 000, 000.00 and to bind the Companies thereby as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Companies and all of the acts of said Attorney, pursuant to the authority hereby given and hereby ratified and confirmed. The Authority hereby granted is continuous and shall remain in full force and effect until revoked by United Fire & Casualty Company, United Fire & Indemnity Company, and Financial Pacific Insurance Company. This Power of Attorney Ls made and executed pursuant to and by authority of the following bylaw duly adopted on May 15, 201.3, by the Boards of Directors of United Fire & Casualty Company, United Fire & Indemnity Company, and Financial Pacific Insurance Company. "Article VI — Surety Bonds and Undertakings" Section 2, Appointment of Attorney -in -Fact. "the President or any Vice President, or any other officer of thc Companies may, from time to time, appoint by written certificates anorncys-in-fact to act in behalf of the Companies in the execution of policies of insurance, bonds, undertakings and other obligatory instruments of like nature. "I -he signature of any officer authorized hereby. and the Co:poratc seal, may be affixed by facsimile to any power of attorney or special power of attorney or cenifica'aon of either authorized hereby; such signature and seal, when so used, being adopted by the Companies as thc original signature of such officer and the original seal of the Companies, to be valid and binding upon thc Companies with the same force and effect as though manually affixed. Such attorneys -in -fact, subject to the limitations set of forth in their respective certificates of authority shall have full power to hind the Companies by their signature and execution of any such instruments and to attach the seal thc Companies thereto. The President or any Vicc President, the Board of Directors or any other officer of the Companies may at any time revoke all power and authority previously given :o any attorney -in -fact. IN WITNESS WHEREOF, the COMPANIES have tack caused these presents to be signed by its vice president and its corporate seal to be hereto affixed this 1 l t h day of October, 2013 UNITED FIRE & CASUALTY COMPANY UNITED FIRE & INDEMNITY COMPANY FINANCIAL. PACIFIC INSURANCE COMPANY By: State of Iowa, County of Linn, ss: Vice President On 11th day of October, 2013, before me personally came Dennis J. Richmann to me known, who being by me duly sworn, did depose and say; that he resides in Cedar Rapids, State of Iowa; that he is a Vice President of United Fire & Casualty Company, a Vice President of United Fire & Indemnity Company, and a Vice President of Financial Pacific Insurance Company the corporations described in and which executed the above instrument; that he knows the seal of said corporations; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporations and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporations. Patti Waddell Iowa Notarial Seal Commission number 713274 My Commission Expires 10/26/2022 att W C241'd u'l Notary Public My commission expires: 10/26/2022 I, Mary A. Bertsch, Assistant Secretary of United Fire & Casualty Company and Assistant Secretary of United Fire & Indemnity Company, and Assistant Secretary of Financial Pacific Insurance Company, do hereby certify that 1 have compared the foregoing copy of the Power of Attorney and affidavit, and the copy of the Section of the bylaws and resolutions of said Corporations as set forth in said Power of Attorney, with the ORIGINALS ON FILE IN THE: HOME OFFICE OF SAID CORPORATIONS, and that the same are correct transcripts thereof, and of the whole of the said originals, and that the said Power of Attorney has not been revoked and is now in full force and effect. In testimony whereof I have hereunto subscribed my name and affixed the corporate seal of the said Corporations .' t}iis day of , 20 • COfi!'ORATL,, � � , • %, BI'0\0049 1217 F3y: L-rrj A ci " Assistant Secretary, UF&C & UF&I & FPiC This paper has a colored background and void pantograph.